FIDIC 1987 reprinted in 1988 and 1992.

FEDERATION INTERNATIONALE DES INGENIEURS-CONSEILS CONDITIONS OF CONTRACT FOR WORKS OF CIVIL ENGINEERING CONSTRUCTION PART I GENERAL CONDITIONS WITH FORMS OF TENDER AND AGREEMENT PART II CONDITIONS OF PARTICULAR APPLICATION WITH GUIDELINES FOR PREPARATION OF PART II CLAUSES FOURTH EDITION 1987 Reprinted 1988 with editorial amendments Reprinted 1992 with further amendments FOREWORD The terms of the Fourth Edition of the Conditions of Contract for Works of Civil Engineering Construction have been prepared by the Fédération Internationale des Ingénieurs Conseils (FIDIC) and are recommended for general use for the purpose of construction of such works where tenders are invited on an intemational basis. The Conditions, subject to minor modifications, are also suitable for use on domestic contracts. The version in English of the Conditions is considered by FIDIC as the official and authentic text for the purpose of translation. In the preparation of the Conditions it was recognised that while there are numerous Clauses which will be generally applicable there are some Clauses which must necessarily vary to take account of the circumstances and locality of the Works. The Clauses of general application have been grouped together in this document and are referred to as Part 1 - General Conditions. They have been printed in a form which will facilitate their inclusion as printed in the contract documents normally prepared. The General Conditions are linked with the Conditions of Particular Application, referred to as Part 11, by the corresponding numbering of the Clauses, so that Parts 1 and 11 together comprise the Conditions governing the rights and obligations of the parties. Part II must be specially drafted to suit each individual Contract. When dredging and certain types of reclamation work are involved special consideration must be given to Part II. To assist in the preparation of Part II explanatory material and example clauses are published with the Conditions in a separately bound document entitled “Conditions of Contract for Works of Civil Engineering Construction, Part II Conditions of Particular Application, with Guidelines for preparation of Part II Clauses, Fourth Edition”. FIDIC has published a "Guide to the Use of FIDIC Conditions of Contract for Works of Civil Engineering Construction" which includes comments on the provisions of the Fourth Edition of the Conditions. Users of the Fourth Edition may find it helpful to refer to this Guide. It may also be helpful for users to refer to other FIDIC publications, such as: Tendering Procedure (First Edition 1982) Construction, Insurance and Law (1986) FIDIC gratefully acknowledges the suggestions and comments it has received during the preparation of this edition from European International Contractors (E1Q as mandatory of Confederation of International Contractors Associations (CICA) with participation of Associated General Contractors of America (AGC).  FIDIC 1987 CONTENTS PART 1: GENERAL CONDITIONS Definitions and Interpretation 1.1 1.2 1.3 1.4 1.5 Definitions Headings and Marginal Notes Interpretation Singular and Plural Notices, Consents, Approvals, Certificates and determinations. 1 2 2 2 3 Engineer and Engineer’s Representative 2.1 2.2 2.3 2.4 2.5 2.6 Engineer’s Duties and Authority Engineer’s Representative Engineer’s Authority to Delegate Appointment of Assistants Instructions in Writing Engineer to Act Impartially 3 3 3 3 3 4 Assignment and Subcontracting 3.1 4.1 4.2 Assignment of Contract Subcontracting Assignment of Subcontractors' Obligations 4 4 4 Contract Documents 5.1 5.2 6.1 6.2 6.3 6.4 6.5 7.1 7.2 7.3 Language/s and Law Priority of Contract Documents Custody and Supply of Drawings and Documents One Copy of Drawings to be Kept on Site Disruption of Progress Delays and Cost of Delay of Drawings Failure by Contractor to Submit Drawings Supplementary Drawings and Instructions Permanent Works Designed by Contractor Responsibility Unaffected by Approval 4 5 5 5 5 5 5 6 6 6 General Obligations 8.1 8.2 9.1 10.1 10.2 10.3 11.1 12.1 12.2 13.1 14.1 14.2 14.3 14.4 15.1 Contractor's General Responsibilities Site Operations and Methods of Construction Contract Agreement Performance Security Period of Validity of Performance Security Claims under Performance Security Inspection of Site Sufficiency of Tender Not Foreseeable Physical Obstructions or Conditions Work to be in Accordance with Contract Programme to be Submitted Revised Programme Cash Flow Estimate to be Submitted Contractor not Relieved of Duties or Responsibilities Contractor's Superintendence  FIDIC 1987 6 6 6 6 7 7 7 7 7 8 8 8 8 8 8 i 16.1 16.2 17.1 18.1 19.1 19.2 20.1 20.2 20.3 20.4 20.5 20.6 21.3 21.4 22.1 22.2 22.3 23.1 23.2 23.2 24.1 24.2 25.1 25.2 25.3 25.4 25.5 27.1 28.1 28.2 29.1 30.1 30.2 30.3 30.4 31.1 31.2 32.1 33.1 Contractor’s Employees Engineer at Liberty to Object Setting-out Boreholes and Exploratory Excavation Safety, Security and Protection of the Environment Employer’s Responsibilities Care of Works Responsibility to Rectify Loss or Damage Loss or Damage Due to Employer's Risks Employer's Risks Insurance of Works and Contractor's Equipment Scope of Cover Responsibility for Amounts not Recovered Exclusions Damage to Persons and Property Exceptions Indemnity by Employer Third Party Insurance (including Employer's Property) Minimum Amount of Insurance Cross Liabilities Accident or Injury to Workmen Insurance Against Accident to Workmen Evidence and Terms of Insurances Adequacy of Insurances Remedy on Contractor's Failure to Insure Compliance with Policy Conditions Compliance with Statutes, Regulations Fossils Patent Rights Royalties Interference with Traffic and Adjoining Properties Avoidance of Damage to Roads Transport of Contractor's Equipment or Temporary Works Transport of Materials or Plant Waterborne Traffic Opportunities for Other Contractors Facilities for Other Contractors Contractor to Keep Site Clear Clearance of Site on Completion 8 8 9 9 9 9 9 10 10 10 10 11 11 11 11 11 12 12 12 12 12 12 12 12 12 12 13 13 13 13 13 14 14 14 14 14 14 15 15 Labour 34.1 35.1 Engagement of Staff and Labour Returns of Labour and Contractor's Equipment 15 15 Materials, Plant and Workmanship 36.1 36.2 36.3 36.4 36.5 37.1 37.2 37.3 37.4 37.5 38.1 Quality of Materials, Plant and Workmanship Cost of Samples Cost of Tests Cost of Tests not Provided for Engineer's Determination where Tests not Provided for Inspection of Operations Inspection and Testing Dates for Inspection and Testing Rejection Independent Inspection Examination of Work before Covering up  FIDIC 1987 15 15 15 16 16 16 16 16 16 17 17 ii 38.2 39.1 39.2 Uncovering and Making Openings Removal of Improper Work, Materials or Plant Default of Contractor in Compliance 17 17 17 Suspension 40.1 40.2 40.3 Suspension of Work Engineer’s Determination following Suspension Suspension lasting more than 84 Days 17 18 18 Commencement and Delays 41.1 42.1 42.2 42.3 43.1 44.1 44.2 44.3 45.1 46.1 47.1 47.2 48.1 48.2 48.3 48.4 Commencement of Works Possession of Site and Access Thereto Failure to Give Possession Rights of Way and Facilities Time for Completion Extension of Time for Completion Contractor to Provide Notification and Detailed Particulars Interim Determination of Extension Restriction on Working Hours Rate of Progress Liquidated Damages for Delay Reduction of Liquidated Damages Taking-Over Certificate Taking-Over of Sections or Parts Substantial Completion of Parts Surfaces Requiring Reinstatement 18 18 19 19 19 19 19 19 20 20 20 20 21 21 21 21 Defects Liability 49.1 49.2 49.3 49.4 50.1 Defects Liability Period Completion of Outstanding Work and Remedying Defects Cost of Remedying Defects Contractor’s Failure to Carry Out Instructions Contractor to Search 21 22 22 22 22 Alterations, Additions and Omissions 51.1 51.2 52.1 52.2 52.3 52.4 Variations Instructions for Variations Valuation of Variations Power of Engineer to Fix Rates Variations Exceeding 15 percent Daywork 22 23 23 23 23 24 Procedure for Claims 53.1 53.2 53.3 53.4 53.5 Notice of Claims Contemporary Records Substantiation of Claims Failure to Comply Payment of Claims 24 24 25 25 25 Contractor’s Equipment, Temporary Works and Materials 54.1 54.2 54.3 Contractor’s Equipment, Temporary Works and Materials; Exclusive Use for the Works Employer not Liable for Damage Customs Clearance  FIDIC 1987 25 25 25 iii 54.4 54.5 54.6 54.7 54.8 Re-export of Contractor's Equipment Conditions of Hire of Contractor's Equipment Costs for the Purpose of Clause 63 Incorporation of Clause in Subcontracts Approval of Materials not Implied 55.1 56.1 57.1 57.2 Quantities Works to be Measured Method of Measurement Breakdown of Lump Sum Items 58.1 58.2 58.3 Definition of "Provisional Sum" Use of Provisional Sums Production of Vouchers 25 26 26 26 26 Measurement 26 26 27 27 Provisional Sums 27 27 27 Nominated Subcontractors 59.1 59.2 59.3 59.4 59.5 Definition of “Nominated Subcontractors” Nominated Subcontractors; Objection to Nomination Design Requirements to be Expressly Stated Payments to Nominated Subcontractors Certification of Payments to Nominated Subcontractors 27 27 28 28 28 Certificates and Payment 60.1 60.2 60.3 60.4 60.5 60.6 60.7 60.8 60.9 60.10 61.1 62.1 62.2 Monthly Statements Monthly Payments Payment of Retention Money Correction of Certificates Statement at Completion Final Statement Discharge Final Payment Certificate Cessation of Employer's Liability Time for Payment Approval only by Defects Liability Certificate Defects Liability Certificate Unfulfilled Obligations 63.1 63.2 63.3 63.4 64.1 Default of Contractor Valuation at Date of Termination Payment after Termination Assignment of Benefit of Agreement Urgent Remedial Work 29 29 29 29 30 30 30 30 30 31 31 31 31 Remedies 31 32 32 32 32 Special Risks 65.1 65.2 65.3 65.4 65.5 65.6 65.7 65.8 No Liability for Special Risks Special Risks Damage to Works by Special Risks Projectile, Missile Increased Costs arising from Special Risks Outbreak of War Removal of Contractor's Equipment on Termination Payment if Contract Terminated  FIDIC 1987 33 33 33 33 33 33 34 34 iv Release from Performance 66.1 Payment in Event of Release from Performance 35 Settlement of Disputes 67.1 67.2 67.3 67.4 Engineer’s Decision Amicable Settlement Arbitration Failure to Comply with Engineer's Decision 68.1 68.2 68.3 Notice to Contractor Notice to Employer and Engineer Change of Address 35 35 36 36 Notices 36 36 36 Default of Employer 69.1 69.2 69.3 69.4 69.5 Default of Employer Removal of Contractor's Equipment Payment on Termination Contractor’s Entitlement to Suspend Work Resumption of Work 36 37 37 37 37 Changes in Cost and Legislation 70.1 70.2 Increase or Decrease of Cost Subsequent Legislation 71.1 72.1 72.2 72.3 Currency Restrictions Rates of Exchange Currency Proportions Currencies of Payment for Provisional Sums 37 37 Currency and Rates of Exchange 38 38 38 38 REFERENCE TO PART II INDEX TENDER AGREEMENT EDITORIAL AMENDMENTS IN 1988 FURTHER AMENDMENTS IN 1992  FIDIC 1987 v PART 1 - GENERAL CONDITIONS Definitions and Interpretation Definitions 1.1 In the Contract (as hereinafter defined) the following words and expressions shall have the meanings hereby assigned to them, except where the context otherwise requires: (a) (i) “Employer” means the person named as such in Part 11 of these Conditions and the legal successors in title to such person, but not (except with the consent of the Contractor) any assignee of such person. (ii) “Contractor” means the person whose tender has been accepted by the Employer and the legal successors in title to such person, but not (except with the consent of the Employer) any assignee of such person. (iii) “Subcontractor” means any person named in the Contract as a Subcontractor for a part of the Works or any person to whom a part of the Works has been subcontracted with the consent of the Engineer and the legal successors in title to such person, but not any assignee of any such person. (iv) “Engineer” means the person appointed by the Employer to act as Engineer for the purposes of the Contract and named as such in Part II of these Conditions. (v) “Engineer’s Representative” means a person appointed from time to time by the Engineer under Sub-Clause 2.2 (b) (i) “Contract” means these Conditions (Parts 1 and 11), the Specification, the Drawings, the Bill of Quantities, the Tender, the Letter of Acceptance, the Contract Agreement (if completed) and such further documents as may be expressly incorporated in the Letter of Acceptance or Contract Agreement (if completed). (ii) “Specification” means the specification of the Works included in the Contract and any modification thereof or addition thereto made under Clause 51 or submitted by the Contractor and approved by the Engineer. (iii) “Drawings” means all drawings, calculations and technical information of a like nature provided by the Engineer to the Contractor under the Contract and all drawings, calculations, samples, patterns, models, operation and maintenance manuals and other technical information of a like nature submitted by the Contractor and approved by the Engineer. (iv) “Bill of Quantities” means the priced and completed bill of quantities forming part of the Tender. (v) “Tender” means the Contractor’s priced offer to the Employer for the execution and completion of the Works and the remedying of any defects therein in accordance with the provisions of the Contract, as accepted by the Letter of Acceptance. (vi) “Letter of Acceptance” means the formal acceptance by the Employer of the Tender. (vii) “Contract Agreement” C means the contract agreement (if any) referred to in Sub-Clause 9. 1. (viii) “Appendix to Tender” means the appendix comprised in the form of Tender annexed to these Conditions. (c) (i) “Commencement Date” means the date upon which the Contractor receives the notice to commence issued by the Engineer pursuant to Clause 41. (ii) “Time for Completion” means the time for completing the execution of and passing the Tests on Completion of the Works or any Section or part thereof as stated in the Contract (or as extended under Clause 44) calculated from the Commencement Date.  FIDIC 1987 1 (d) (i) “Tests on Completion” means the tests specified in the Contract or otherwise agreed by the Engineer and the Contractor which are to be made by the Contractor before the Works or any Section or part thereof are taken over by the Employer. (ii) “Taking-Over Certificate” means a certificate issued pursuant to Clause 48. (e) (i) “Contract Price” means the sum stated in the Letter of Acceptance as payable to the Contractor for the execution and completion of the Works and the remedying of any defects therein in accordance with the provisions of the Contract. (ii) “Retention Money” means the aggregate of all monies retained by the Employer pursuant to Sub-Clause 60.2(a). (iii) “Interim Payment Certificate” means any certificate of payment issued by the Engineer other than the Final Payment Certificate. (iv) “Final Payment Certificate” means the certificate of payment issued by the Engineer pursuant to Sub-Clause 60.8. Headings and Marginal Notes 1.2 Interpretation 1.3 Singular and Plural 1.4 (f) (i) “Works” means the Permanent Works and the Temporary Works or either of them as appropriate. (ii) “Permanent Works” means the permanent works to be executed (including Plant) in accordance with the Contract. (iii) “Temporary Works” means all temporary works of every kind (other than Contractor’ Equipment) required in or about the execution and completion of the Works and the remedying of any defects therein. (iv) “Plant” means machinery, apparatus and the like intended to form or forming part of the Permanent Works. (v) “Contractor’s Equipment” means all appliances and things of whatsoever nature (other than Temporary Works) required for the execution and completion of the Works and the remedying of any defects therein, but does not include Plant, materials or other things intended to form or forming part of the Permanent Works. (vi) “Section” means a part of the Works specifically identified in the Contract as a Section. (vii) “Site” means the places provided by the Employer where the Works are to be executed and any other places as may be specifically designated in the Contract as forming part of the Site. (g) (i) “cost” means all expenditure properly incurred or to be incurred, whether on or off the Site, including overhead and other charges properly allocable thereto but does not include any allowance for profit. (ii) “day” means calendar day. (iii) “foreign currency” means a currency of a country other than that in which the Works are to be located. (iv) “writing” means any hand-written, type-written, or printed communication, including telex, cable and facsimile transmission. The headings and marginal notes in these Conditions shall not be deemed part thereof or be taken into consideration in the interpretation or construction thereof or of the Contract. Words importing persons or parties shall include firms and corporations and any organisation having legal capacity. Words importing the singular only also include the plural and vice versa where the context requires.  FIDIC 1987 2 Notices, Consents, Approvals, Certificates and Determinations 1.5 Wherever in the Contract provision is made for the giving or issue of any notice, consent, approval, certificate or determination by any person, unless otherwise specified such notice, consent, approval, certificate or determination shall be in writing and the words “notify”, “certify” or “determine” shall be construed accordingly. Any such consent, approval, certificate or determination shall not unreasonably be withheld or delayed. Engineer and Engineer’s Representative Engineer’s Duties and Authority 2.1 Engineer’s Representative 2.2 Engineer’s Authority to Delegate 2.3 Appointment of Assistants 2.4 (a) The Engineer shall carry out the duties specified in the Contract. (b) The Engineer may exercise the authority specified in or necessarily to be implied from the Contract, provided, however, that if the Engineer is required, under, the terms of his appointment by the Employer, to obtain the specific approval of the Employer before exercising any such authority, particulars of such requirements shall be set out in Part II of these Conditions. Provided further that any requisite approval shall be deemed to have been given by the Employer for any such authority exercised by the Engineer. (c) Except as expressly stated in the Contract, the Engineer shall have no authority to relieve the Contractor of any of his obligations under the Contract. The Engineer’s Representative shall be appointed by and be responsible to the Engineer and shall carry out such duties and exercise such authority as may be delegated to him by the Engineer under Sub-Clause 2.3. The Engineer may from time to time delegate to the Engineer’s Representative any of the duties and authorities vested in the Engineer and he may at any time revoke such delegation. Any such delegation or revocation shall be in writing and shall not take effect until a copy thereof has been delivered to the Employer and the Contractor. Any communication given by the Engineer’s Representative to the Contractor in accordance with such delegation shall have the same effect as though it had been given by the Engineer. Provided that: (a) any failure of the Engineer’s Representative to disapprove any work, materials or Plant shall not prejudice the authority of the Engineer to disapprove such work, materials or Plant and to give instructions for the rectification thereof, and (b) if the Contractor questions any communication of the Engineer’s Representative he may refer the matter to the Engineer who shall confirm, reverse or vary the contents of such communication. The Engineer or the Engineer’s Representative may appoint any number of persons to assist the Engineer's Representative in the carrying out of his duties under Instructions in Writing 2.5 Sub-Clause 2.2. He shall notify to the Contractor the names, duties and scope of authority of such persons. Such assistants shall have no authority to issue any instructions to the Contractor save in so far as such instructions may be necessary to enable them to carry out their duties and to secure their acceptance of materials, Plant or workmanship as being in accordance with the Contract, and any instructions given by any of them for those purposes shall be deemed to have been given by the Engineer's Representative. Instructions given by the Engineer shall be in writing, provided that if for any reason the Engineer considers it necessary to give any such instruction orally, the Contractor shall comply with such instruction. Confirmation in writing of such oral instruction given by the Engineer, whether before or after the carrying out of the instruction, shall be deemed to be an instruction within the meaning of this Sub-Clause. Provided further that if the Contractor, within 7 days, confirms in writing to the Engineer any oral instruction of the Engineer and such confirmation is not contradicted in writing within 7 days by the Engineer, it shall be deemed to be an instruction of the Engineer.  FIDIC 1987 3 Engineer to Act Impartially 2.6 The provisions of this Sub-Clause shall equally apply to instructions given by the Engineer's Representative and any assistants of the Engineer or the Engineer’s Representative appointed pursuant to Sub-Clause 2.4. Wherever, under the Contract, the Engineer is required to exercise his discretion by: (a) giving his decision, opinion or consent, (b) expressing his satisfaction or approval, (c) determining value, or (d) otherwise taking action which may affect the rights and obligations of the Employer or the Contractor he shall exercise such discretion impartially within the terms of the Contract and having regard to all the circumstances. Any such decision, opinion, consent, expression of satisfaction, or approval, determination of value or action may be opened up, reviewed or revised as provided in Clause 67. Assignment and Subcontracting Assignment of Contract 3.1 Subcontracting 4.1 Assignment of Subcontractors’ Obligations 4.2 The Contractor shall not, without the prior consent of the Employer (which consent, notwithstanding the provisions of Sub-Clause 1.5, shall be at the sole discretion of the Employer), assign the Contract or any part thereof, or any benefit or interest therein or thereunder, otherwise than by: (a) a charge in favour of the Contractor’s bankers of any monies due or to become due under the Contract, or (b) assignment to the Contractor’s insurers (in cases where the insurers have discharged the Contractor's loss or liability) of the Contractor's right to obtain relief against any other party liable. The Contractor shall not subcontract the whole of the Works. Except where otherwise provided by the Contract, the Contractor shall not subcontract any part of the Works without the prior consent of the Engineer. Any such consent shall not relieve the Contractor from any liability or obligation under the Contract and he shall be responsible for the acts, defaults and neglects of any Subcontractor, his agents, servants or workmen as fully as if they were the acts, defaults or neglects of the Contractor, his agents, servants or workmen. Provided that the Contractor shall not be required to obtain such consent for: (a) the provision of labour, (b) the purchase of materials which are in accordance with the standards specified in the Contract, or (c) the subcontracting of any part of the Works for which the Subcontractor is named in the Contract. In the event of a Subcontractor having undertaken towards the Contractor in respect of the work executed, or the goods, materials, Plant or services supplied by such Subcontractor, any continuing obligation extending for a period exceeding that of the Defects Liability Period under the Contract, the Contractor shall at any time, after the expiration of such Period, assign to the Employer, at the Employer’s request and cost, the benefit of such obligation for the unexpired duration thereof. Contract Documents Lanquage/s and Law 5.1 There is stated in Part II of these Conditions: (a) the language or languages in which the Contract documents shall be drawn up, and (b) the country or state the law of which shall apply to the Contract and according to which the Contract shall be construed.  FIDIC 1987 4 Priority of Contract Documents 5.2 Custody and Supply of Drawings and Documents 6.1 One Copy of Drawings to be Kept on Site 6.2 Disruption of Progress 6.3 Delays and Cost of Delay of Drawings 6.4 Failure by Contractor to Submit Drawings 6.5 If the said documents are written in more than one language, the language according to which the Contract shall be construed and interpreted is also stated in Part II of these Conditions, being therein designated the “Ruling Language”. The several documents forming the Contract are to be taken as mutually explanatory of one another, but in case of ambiguities or discrepancies the same shall be explained and adjusted by the Engineer who shall thereupon issue to the Contractor instructions thereon and in such event, unless otherwise provided in the Contract, the priority of the documents forming the Contract shall be as follows: (1) The Contract Agreement (if completed); (2) The Letter of Acceptance; (3) The Tender; (4) Part II of these Conditions; (5) Part I of these Conditions; and (6) Any other document forming part of the Contract. The Drawings shall remain in the sole custody of the Engineer, but two copies thereof shall be provided to the Contractor free of charge. The Contractor shall make at his own cost any further copies required by him. Unless it is strictly necessary for the purposes of the Contract, the Drawings, Specification and other documents provided by the Employer or the Engineer shall not, without the consent of the Engineer, be used or communicated to a third party by the Contractor. Upon issue of the Defects Liability Certificate, the Contractor shall return to the Engineer all Drawings, Specification and other documents provided under the Contract. The Contractor shall supply to the Engineer four copies of all Drawings, Specification and other documents submitted by the Contractor and approved by the Engineer in accordance with Clause 7, together with a reproducible copy of any material which cannot be reproduced to an equal standard by photocopying. In addition the Contractor shall supply such further copies of such Drawings, Specification and other documents as the Engineer may request in writing for the use of the Employer, who shall pay the cost thereof. One copy of the Drawings, provided to or supplied by the Contractor as aforesaid, shall be kept by the Contractor on the Site and the same shall at all reasonable times be available for inspection and use by the Engineer and by any other person authorised by the Engineer in writing. The Contractor shall give notice to the Engineer, with a copy to the Employer, whenever planning or execution of the Works is likely to be delayed or disrupted unless any further drawing or instruction is issued by the Engineer within a reasonable time. The notice shall include details of the drawing or instruction required and of why and by when it is required and of any delay or disruption likely to be suffered if it is late. If, by reason of any failure or inability of the Engineer to issue, within a time reasonable in all the circumstances, any drawing or instruction for which notice has been given by the Contractor in accordance with Sub-Clause 63, the Contractor suffers delay and/or incurs costs then the Engineer shall, after due consultation with the Employer and the Contractor, determine: (a) any extension of time to which the Contractor is entitled under Clause 44, and (b) the amount of such costs, which shall be added to the Contract Price, and shall notify the Contractor accordingly, with a copy to the Employer. If the failure or inability of the Engineer to issue any drawings or instructions is caused in whole or in part by the failure of the Contractor to submit Drawings, Specification or other documents which he is required to submit under the Contract, the Engineer shall take such failure. by the Contractor into account when making his determination pursuant to Sub-Clause 6.4.  FIDIC 1987 5 Supplementary Drawings and Instructions 7.1 Permanent Works Designed by Contractor 7.2 Responsibility Unaffected by Approval 7.3 The Engineer shall have authority to issue to the Contractor, from time to time, such supplementary Drawings and instructions as shall be necessary for the purpose of the proper and adequate execution and completion of the Works and the remedying of any defects therein. The Contractor shall carry out and be bound by the same. Where the Contract expressly provides that part of the Permanent Works shall be designed by the Contractor, he shall submit to the Engineer, for approval: (a) such drawings, specifications, calculations and other information as shall be necessary to satisfy the Engineer as to the suitability and adequacy of that design, and (b) operation and maintenance manuals together with drawings of the Permanent Works as completed, in sufficient detail to enable the Employer to operate, maintain, dismantle, reassemble and adjust the Permanent Works incorporating that design. The Works shall not be considered to be completed for the purposes of taking over in accordance with Clause 48 until such operation and maintenance manuals, together with drawings on completion, have been submitted to and approved by the Engineer Approval by the Engineer, in accordance with Sub-Clause 7.2, shall not relieve the Contractor of any of his responsibilities under the Contract. General Obligations Contractor’s General Responsibilities 8.1 Site Operations and Methods of Construction 8.2 Contract Agreement 9.1 Performance 10.1 Security The Contractor shall, with due care and diligence, design (to the extent provided for by the Contract), execute and complete the Works and remedy any defects therein in accordance with the provisions of the Contract. The Contractor shall provide all superintendence, labour, materials, Plant, Contractor’s Equipment and all other things, whether of a temporary or permanent nature, required in and for such design, execution, completion and remedying of any defects, so far as the necessity for providing the same is specified in or is reasonably to be inferred from the Contract. The Contractor shall give prompt notice to the Engineer, with a copy to the Employer, of any error, omission, fault or other defect in the design of or Specification for the Works which he discovers when reviewing the Contract or executing the Works. The Contractor shall take full responsibility for the adequacy, stability and safety of all Site operations and methods of construction. Provided that the Contractor shall not be responsible (except as stated hereunder or as may be otherwise agreed) for the design or specification of Permanent Works, or for the design or specification of any Temporary Works not prepared by the Contractor. Where the Contract expressly provides that part of the Permanent Works shall be designed by the Contractor, he shall be fully responsible for that part of such Works, notwithstanding any approval by the Engineer. The Contractor shall, if called upon so to do, enter into and execute the Contract Agreement, to be prepared and completed at the cost of the Employer, in the form annexed to these Conditions with such modification as may be necessary. If the Contract requires the Contractor to obtain security for his proper performance of the Contract, he shall obtain and provide to the Employer such security within 28 days after the receipt of the Letter of Acceptance, in the sum stated in the Appendix to Tender. When providing such security to the Employer, the Contractor shall notify the Engineer of so doing. Such security shall be in the form annexed to these Conditions or in such other form as may be agreed between the Employer and the Contractor. The institution providing such security shall be subject to the approval of the Employer. The cost of complying with the requirements of this Clause shall be borne by the Contractor, unless the Contract otherwise provides.  FIDIC 1987 6 Period of 10.2 Validity of Performance Security Claims under 10.3 Performance Security Inspection 11.1 of Site The performance security shall be valid until the Contractor has executed and completed the Works and remedied any defects therein in accordance with the Contract. No claim shall be made against such security after the issue of the Defects Liability Certificate in accordance with Sub-Clause 62.1 and such security shall be returned to the Contractor within 14 days of the issue of the said Defects Liability Certificate. Prior to making a claim under the performance security the Employer shall, in every case, notify the Contractor stating the nature of the default in respect of which the claim is to be made. The Employer shall have made available to the Contractor, before the submission by the Contractor of the Tender, such data on hydrological and sub-surface conditions as have been obtained by or on behalf of the Employer from investigations undertaken relevant to the Works but the Contractor shall be responsible for his own interpretation thereof. The Contractor shall be deemed to have inspected and examined the Site and its surroundings and information available in connection therewith and to have satisfied himself (so far as is practicable, having regard to considerations of cost and time) before submitting his Tender, as to: (a) the form and nature thereof, including the sub-surface conditions, (b) the hydrological and climatic conditions, (c) the extent and nature of work and materials necessary for the execution and completion of the Works and the remedying of any defects therein, and Sufficiency 12.1 of Tender Not Foreseeable 12.2 Physical Obstructions or Conditions (d) the means of access to the Site and the accommodation he may require, and, in general, shall be deemed to have obtained all necessary information, subject as above mentioned, as to risks, contingencies and all other circumstances which may influence or affect his Tender. The Contractor shall be deemed to have based his Tender on the data made available by the Employer and on his own inspection and examination, all as aforementioned. The Contractor shall be deemed to have satisfied himself as to the correctness and sufficiency of the Tender and of the rates and prices stated in the Bill of Quantities, all of which shall, except insofar as it is otherwise provided in the Contract, cover all his obligations under the Contract (including those in respect of the supply of goods, materials, Plant or services or of contingencies for which there is a Provisional Sum) and all matters and things necessary for the proper execution and completion of the Works and the remedying of any defects therein. If, however, during the execution of the Works the Contractor encounters physical obstructions or physical conditions, other than climatic conditions on the Site, which obstructions or conditions were, in his opinion, not foreseeable by an experienced contractor, the Contractor shall forthwith give notice thereof to the Engineer, with a copy to the Employer. On receipt of such notice, the Engineer shall, if in his opinion such obstructions or conditions could not have been reasonably foreseen by an experienced contractor, after due consultation with the Employer and the Contractor, determine (a) any extension of time to which the Contractor is entitled under Clause 44, and (b) the amount of any costs which may have been incurred by the Contractor by reason of such obstructions or conditions having been encountered, which shall be added to the Contract Price, and shall notify the Contractor accordingly, with a copy to the Employer. Such determination shall take account of any instruction which the Engineer may issue to the Contractor in connection therewith, and any proper and reasonable measures acceptable to the Engineer which the Contractor may take in the absence of specific instructions from the Engineer.  FIDIC 1987 7 Work to be in 13.1 Accordance with Contract Programme to 14.1 be Submitted Revised 14.2 Programme Cash Flow 14.3 Estimate to be Submitted Contractor not 14.4 Relieved of Duties or Responsibilities Contractor’s 15.1 Superintendence Contractor’s 16. 1 Employees Engineer at 16.2 Liberty to Object Unless it is legally or physically impossible, the Contractor shall execute and complete the Works and remedy any defects therein in strict accordance with the Contract to the satisfaction of the Engineer. The Contractor shall comply with and adhere strictly to the Engineer’s instructions on any matter, whether mentioned in the Contract or not, touching or concerning the Works. The Contractor shall take instructions only from the Engineer (or his delegate). The Contractor shall, within the time stated in Part II of these Conditions after the date of the Letter of Acceptance, submit to the Engineer for his consent a programme, in such form and detail as the Engineer shall reasonably prescribe, for the execution of the Works. The Contractor shall, whenever required by the Engineer, also provide in writing for his information a general description of the arrangements and methods which the Contractor proposes to adopt for the execution of the Works. If at any time it should appear to the Engineer that the actual progress of the Works does not conform to the programme to which consent has been given under Sub-Clause 14.1, the Contractor shall produce, at the request of the Engineer, a revised programme showing the modifications to such programme necessary to ensure completion of the Works within the Time for Completion. The Contractor shall, within the time stated in Part II of these Conditions after the date of the Letter of Acceptance, provide to the Engineer for his information a detailed cash flow estimate. in quarterly periods, of all payments to which the Contractor will be entitled under the Contract and the Contractor shall subsequently supply revised cash flow estimates at quarterly intervals, if required to do so by the Engineer. The submission to and consent by the Engineer of such programmes or the provision of such general descriptions or cash flow estimates shall not relieve the Contractor of any of his duties or responsibilities under the Contract. The Contractor shall provide all necessary superintendence during the execution of the Works and as long thereafter as the Engineer may consider necessary for the proper fulfilling of the Contractor's obligations under the Contract. The Contractor, or a competent and authorised representative approved of by the Engineer, which approval may at any time be withdrawn, shall give his whole time to the superintendence of the Works. Such authorised representative shall receive, on behalf of the Contractor, instructions from the Engineer. If approval of the representative is withdrawn by the Engineer, the Contractor shall, as soon as is practicable, having regard to the requirement of replacing him as hereinafter mentioned, after receiving notice of such withdrawal, remove the representative from the Works and shall not thereafter employ him again on the Works in any capacity and shall replace him by another representative approved by the Engineer. The Contractor shall provide on the Site in connection with the execution and completion of the Works and the remedying of any defects therein: (a) only such technical assistants as are skilled and experienced in their respective callings and such foremen and leading hands as are competent to give proper superintendence of the Works, and (b) such skilled, semi-skilled and unskilled labour as is necessary for the proper and timely fulfilling of the Contractor's obligations under the Contract. The Engineer shall be at liberty to object to and require the Contractor to remove forthwith from the Works any person provided by the Contractor who, in the opinion of the Engineer, misconducts himself, or is incompetent or negligent in the proper performance of his duties, or whose presence on Site is otherwise considered by the Engineer to be undesirable, and such person shall not be again allowed upon the Works without the consent of the Engineer. Any person so removed from the Works shall be replaced as soon as possible.  FIDIC 1987 8 Setting-out 17. 1 Boreholes and 18.1 Exploratory Excavation Safety, Security 19.1 and Protection of the Environment Employer’s 19.2 Responsibilities Care of Works 20.1 The Contractor shall be responsible for: (a) the accurate setting-out of the Works in relation to original points, lines and levels of reference given by the Engineer in writing, (b) the correctness, subject as above mentioned, of the position, levels, dimensions and alignment of all parts of the Works, and (c) the provision of all necessary instruments, appliances and labour in connection with the foregoing responsibilities. If, at any time during the execution of the Works, any error appears in the position, levels, dimensions or alignment of any part of the Works, the Contractor, on being required so to do by the Engineer, shall, at his own cost, rectify such error to the satisfaction of the Engineer, unless such error is based on incorrect data supplied in writing by the Engineer, in which case the Engineer shall determine an addition to the Contract Price in accordance with Clause 51 and shall notify the Contractor accordingly, with a copy to the Employer. The checking of any setting-out or of any line or level by the Engineer shall not in any way relieve the Contractor of his responsibility for the accuracy thereof and the Contractor shall carefully protect and preserve all bench-marks, sight-rails, pegs and other things used in setting-out the Works. If, at any time during the execution of the Works, the Engineer requires the Contractor to make boreholes or to carry out exploratory excavation, such requirement shall be the subject of an instruction in accordance with Clause 51, unless an item or a Provisional Sum in respect of such work is included in the Bill of Quantities. The Contractor shall, throughout the execution and completion of the Works and the remedying of any defects therein: (a) have full regard for the safety of all persons entitled to be upon the Site and keep the Site (so far as the same is under his control) and the Works (so far as the same are not completed or occupied by the Employer) in an orderly state appropriate to the avoidance of danger to such persons, (b) provide and maintain at his own cost all lights, guards, fencing, warning signs and watching, when and where necessary or required by the Engineer or by any duly constituted authority, for the protection of the Works or for the safety and convenience of the public or others, and (c) take all reasonable steps to protect the environment on and off the Site and to avoid damage or nuisance to persons or to property of the public or others resulting from pollution, noise or other causes arising as a consequence of his methods of operation. If under Clause 31 the Employer shall carry out work on the Site with his own workmen he shall, in respect of such work: (a) have full regard to the safety of all persons entitled to be upon the Site, and (b) keep the Site in an orderly state appropriate to the avoidance of danger to such persons. If under Clause 31 the Employer shall employ other contractors on the Site he shall require them to have the same regard for safety and avoidance of danger. The Contractor shall take full responsibility for the care of the Works and materials and Plant for incorporation therein from the Commencement Date until the date of issue of the Taking-Over Certificate for the whole of the Works, when the responsibility for the said care shall pass to the Employer. Provided that: (a) if the Engineer issues a Taking-Over Certificate for any Section or part of the Permanent, Works the Contractor shall cease to be liable for the care of that Section or part from the date of issue of the Taking-Over Certificate, when the responsibility for the care of that Section or part shall pass to the Employer, and  FIDIC 1987 9 Responsibility 20.2 to Rectify Loss or Damage Loss or 20.3 Damage Due to Employer’s Risks Employer’s Risks 20.4 Insurance of 21.1 Works and Contractor’s Equipment (b) the Contractor shall take full responsibility for the care of any outstanding Works and materials and Plant for incorporation therein which he undertakes to finish during the Defects Liability Period until such outstanding Works have been completed pursuant to Clause 49. If any loss or damage happens to the Works, or any part thereof, or materials or Plant for incorporation therein, during the period for which the Contractor is responsible for the care thereof, from any cause whatsoever, other than the risks defined in Sub-Clause 20.4, the Contractor shall, at his own cost, rectify such loss or damage so that the Permanent Works conform in every respect with the provisions of the Contract to the satisfaction of the Engineer. The Contractor shall also be liable for any loss or damage to the Works occasioned by him in the course of any operations carried out by him for the purpose of complying with his obligations under Clauses 49 and 50. In the event of any such loss or damage happening from any of the risks defined in Sub-Clause 20.4, or in combination with other risks, the Contractor shall, if and to the extent required by the Engineer, rectify the loss or damage and the Engineer shall determine an addition to the Contract Price in accordance with Clause 52 and shall notify the Contractor accordingly, with a copy to the Employer. In the case of a combination of risks causing loss or damage any such determination shall take into account the proportional responsibility of the Contractor and the Employer. The Employer’s risks are: (a) war, hostilities (whether war be declared or not), invasion, act of foreign enemies, (b) rebellion, revolution, insurrection, or military or usurped power, or civil war, (c) ionising radiations, or contamination by radio-activity from any nuclear fuel, or from any nuclear waste from the combustion of nuclear fuel, radio-active toxic explosive or other hazardous properties of any explosive nuclear assembly or nuclear component thereof, (d) pressure waves caused by aircraft or other aerial devices travelling at sonic or supersonic speeds, (e) riot, commotion or disorder, unless solely restricted to employees of the Contractor or of his Subcontractors and arising from the conduct of the Works, (f) loss or damage due to the use or occupation by the Employer of any Section or part of the Permanent Works, except as may be provided for in the Contract, (g) loss or damage to the extent that it is due to the design of the Works, other than any part of the design provided by the Contractor or for which the Contractor is responsible, and (h) any operation of the forces of nature against which an experienced contractor could not reasonably have been expected to take precautions. The Contractor shall, without limiting his or the Employer’s obligations and responsibilities under Clause 20, insure: (a) the Works, together with materials and Plant for incorporation therein, to the full replacement cost (the term "cost" in this context shall include profit), (b) an additional sum of 15 per cent of such replacement cost, or as may be specified in Part II of these Conditions, to cover any additional costs of and incidental to the rectification of loss or damage including professional fees and the cost of demolishing and removing any part of the Works and of removing debris of whatsoever nature, and (c) the Contractor’s Equipment and other things brought onto the Site by the Contractor, for a, sum sufficient to provide for their replacement at the Site.  FIDIC 1987 10 Scope of Cover 21.2 Responsibility for 21.3 Amounts not Recovered Exclusions 21.4 Damage to 22.1 Persons and Property Exceptions 22.2 The insurance in paragraphs (a) and (b) of Sub-Clause 21.1 shall be in the joint names of the Contractor and the Employer and shall cover: (a) the Employer and the Contractor against all loss or damage from whatsoever cause arising, other than as provided in Sub-Clause 21.4, from the start of work at the Site until the date of issue of the relevant Taking-Over Certificate in respect of the Works or any Section or part thereof as the case may be, and (b) the Contractor for his liability: (i) during the Defects Liability Period for loss or damage arising from a cause occurring prior to the commencement of the Defects Liability Period, and (ii) for loss or damage occasioned by the Contractor in the course of any operations carried out by him for the purpose of complying with his obligations under Clauses 49 and 50. Any amounts not insured or not recovered from the insurers shall be borne by the Employer or the Contractor in accordance with their responsibilities under Clause 20. There shall be no obligation for the insurances in Sub-Clause 21.1 to include loss or damage caused by: (a) war, hostilities (whether war be declared or not), invasion, act of foreign enemies, (b) rebellion, revolution, insurrection, or military or usurped power, or civil war, (c) ionising radiations, or contamination by radio-activity from any nuclear fuel, or from any nuclear waste from the combustion of nuclear fuel, radio-active toxic explosive or other hazardous properties of any explosive nuclear assembly or nuclear component thereof, or (d) pressure waves caused by aircraft or other aerial devices travelling at sonic or supersonic speeds. The Contractor shall, except if and so far as the Contract provides otherwise, indemnify the Employer against all losses and claims in respect of: (a) death of or injury to any person, or (b) loss of or damage to any property (other than the Works), which may arise out of or in consequence of the execution and completion of the Works and the remedying of any defects therein, and against all claims, proceedings, damages, costs, charges and expenses whatsoever in respect thereof or in relation thereto, subject to the exceptions defined in Sub-Clause 22.2. The “exceptions” referred to in Sub-Clause 22.1 are: (a) the permanent use or occupation of land by the Works, or any part thereof, (b) the right of the Employer to execute the Works, or any part thereof, on, over, under, in or through any land, (c) damage to property which is the unavoidable result of the execution and completion of the Works, or the remedying of any defects therein, in accordance with the Contract, and (d) death of or injury to persons or loss of or damage to property resulting from any act or neglect of the Employer, his agents, servants or other contractors, not being employed by the Contractor, or in respect of any claims, proceedings, damages, costs, charges and expenses in respect thereof or in relation thereto or, where the injury or damage was contributed to by the Contractor, his servants or agents, such part of the said injury or damage as may be just and equitable having regard to the extent of the responsibility of the Employer, his servants or agents or other contractors for the injury or damage.  FIDIC 1987 11 Indemnity by 22.3 Employer Third Party 23.1 Insurance (including Employer’s Property) Minimum Amount 23.2 of insurance Cross Liabilities 23.3 Accident or Injury 24.1 to Workmen Insurance 24.2 Against Accident to Workmen Evidence and 25.1 Terms of Insurances Adequacy of 25.2 Insurances Remedy on 25.3 Contractor’s Failure to Insure Compliance 25.4 with Policy Conditions The Employer shall indemnify the Contractor against all claims, proceedings, damages, costs, charges and expenses in respect of the matters referred to in the exceptions defined in Sub-Clause 22.2. The Contractor shall, without limiting his or the Employer's obligations and responsibilities under Clause 22, insure, in the joint names of the Contractor and the Employer, against liabilities for death of or injury to any person (other than as provided in Clause 24) or loss of or damage to any property (other than the Works) arising out of the performance of the Contract, other than the exceptions defined in paragraphs (a), (b) and (c) of Sub-Clause 22.2. Such insurance shall be for at least the amount stated in the Appendix to Tender. The insurance policy shall include a cross liability clause such that the insurance shall apply to the Contractor and to the Employer as separate insured. The Employer shall not be liable for or in respect of any damages or compensation payable to any workman or other person in the employment of the Contractor or any Subcontractor, other than death or injury resulting from any act or default of the Employer, his agents or servants. The Contractor shall indemnify and keep indemnified the Employer against all such damages and compensation, other than those for which the Employer is liable as aforesaid, and against all claims, proceedings, damages, costs, charges, and expenses whatsoever in respect thereof or in relation thereto. The Contractor shall insure against such liability and shall continue such insurance during the whole of the time that any persons are employed by him on the Works. Provided that, in respect of any persons employed by any Subcontractor, the Contractor’s obligations to insure as aforesaid under this Sub-Clause shall be satisfied if the Subcontractor shall have insured against the liability in respect of such persons in such manner that the Employer is indemnified under the policy, but the Contractor shall require such Subcontractor to produce to the Employer, when required, such policy of insurance and the receipt for the payment of the current premium. The Contractor shall provide evidence to the Employer prior to the start of work at the Site that the insurances required under the Contract have been effected and shall, within 84 days of the Commencement Date, provide the insurance policies to the Employer. When providing such evidence and such policies to the Employer, the Contractor shall notify the Engineer of so doing. Such insurance policies shall be consistent with the general terms agreed prior to the issue of the Letter of Acceptance. The Contractor shall effect all insurances for which he is responsible with insurers and in terms approved by the Employer. The Contractor shall notify the insurers of changes in the nature, extent or programme for the execution of the Works and ensure the adequacy of the insurances at all times in accordance with the terms of the Contract and shall. when required, produce to the Employer the insurance policies in force and the receipts for payment of the current premiums. If the Contractor fails to effect and keep in force any of the insurances required under the Contract, or fails to provide the policies to the Employer within the period required by Sub-Clause 25.1, then and in any such case the Employer may effect and keep in force any such insurances and pay any premium as may be necessary for that purpose and from time to time deduct the amount so paid from any monies due or to become due to the Contractor, or recover the same as a debt due from the Contractor. In the event that the Contractor or the Employer fails to comply with conditions imposed by the insurance policies effected pursuant to the Contract, each shall indemnify the other against all losses and claims arising from such failure.  FIDIC 1987 12 Compliance with 26.1 Statutes, Regulations Fossils 27.1 Patent Rights 28.1 Royalties 28.2 Interference 29.1 with Traffic and Adjoining Properties The Contractor shall conform in all respects, including by the giving of all notices and the paying of all fees, with the provisions of: (a) any National or State Statute, Ordinance, or other Law, or any regulation, or bye-law of any local or other duly constituted authority in relation to the execution and completion of the Works and the remedying of any defects therein, and (b) the rules and regulations of all public bodies and companies whose property or rights are affected or may be affected in any way by the Works, and the Contractor shall keep the Employer indemnified against all penalties and liability of every kind for breach of any such provisions. Provided always that the Employer shall be responsible for obtaining any planning, zoning or other similar permission required for the Works to proceed and shall indemnify the Contractor in accordance with Sub-Clause 22.3. All fossils, coins, articles of value or antiquity and structures and other remains or things of geological or archaeological interest discovered on the Site shall, as between the Employer and the Contractor, be deemed to be the absolute property of the Employer. The Contractor shall take reasonable precautions to prevent his workmen or any other persons from removing or damaging any such article or thing and shall, immediately upon discovery thereof and before removal, acquaint the Engineer of such discovery and carry out the Engineer’s instructions for dealing with the same. If, by reason of such instructions, the Contractor suffers delay and/or incurs costs then the Engineer shall, after due consultation with the Employer and the Contractor, determine: (a) any extension of time to which the Contractor is entitled under Clause 44, and (b) the amount of such costs, which shall be added to the Contract Price, and shall notify the Contractor accordingly, with a copy to the Employer. The Contractor shall save harmless and indemnify the Employer from and against all claims and proceedings for or on account of infringement of any patent rights, design trademark or name or other protected rights in respect of any Contractor’s Equipment, materials or Plant used for or in connection with or for incorporation in the Works and from and against all damages, costs, charges and expenses whatsoever in respect thereof or in relation thereto, except where such infringement results from compliance with the design or Specification provided by the Engineer. Except where otherwise stated, the Contractor shall pay all tonnage and other royalties, rent and other payments or compensation, if any, for getting stone, sand, gravel, clay or other materials required for the Works. All operations necessary for the execution and completion of the Works and the remedying of any defects therein shall, so far as compliance with the requirements of the Contract permits, be carried on so as not to interfere unnecessarily or improperly with: (a) the convenience of the public, or (b) the access to, use and occupation of public or private roads and footpaths to or of properties whether in the possession of the Employer or of any other person. The Contractor shall save harmless and indemnify the Employer in respect of all claims, proceedings, damages, costs, charges and expenses whatsoever arising out of, or in relation to, any such matters insofar as the Contractor is responsible therefor.  FIDIC 1987 13 Avoidance 30.1 of Damage to Roads Transport of 30.2 Contractor's Equipment or Temporary Works Transport of 30.3 Materials or Plant Waterborne 30.4 Traffic Opportunities 31.1 for Other Contractors Facilities for 31.2 Other Contractors The Contractor shall use every reasonable means to prevent any of the roads or bridges communicating with or on the routes to the Site from being damaged or injured by any traffic of the Contractor or any of his Subcontractors and, in particular, shall select routes, choose and use vehicles and restrict and distribute loads so that any such extraordinary traffic as will inevitably arise from the moving of materials, Plant, Contractor’s Equipment or Temporary Works from and to the Site shall be limited, as far as reasonably possible, and so that no unnecessary damage or injury may be occasioned to such roads and bridges. Save insofar as the Contract otherwise provides, the Contractor shall be responsible for and shall pay the cost of strengthening any bridges or altering or improving any road communicating with or on the routes to the Site to facilitate the movement of Contractor’s Equipment or Temporary Works and the Contractor shall indemnify and keep indemnified the Employer against all claims for damage to any such road or bridge caused by such movement, including such claims as may be made directly against the Employer, and shall negotiate and pay all claims arising solely out of such damage. If, notwithstanding Sub-Clause 30.1, any damage occurs to any bridge or road communicating with or on the routes to the Site arising from the transport of materials or Plant, the Contractor shall notify the Engineer with a copy to the Employer, as soon as he becomes aware of such damage or as soon as he receives any claim from the authority entitled to make such claim. Where under any law or regulation the haulier of such materials or Plant is required to indemnify the road authority against damage the Employer shall not be liable for any costs, charges or expenses in respect thereof or in relation thereto. In other cases the Employer shall negotiate the settlement of and pay all sums due in respect of such claim and shall indemnify the Contractor in respect thereof and in respect of all claims, proceedings, damages, costs, charges and expenses in relation thereto. Provided that if and so far as any such claim or part thereof is, in the opinion of the Engineer, due to any failure on the part of the Contractor to observe and perform his obligations under Sub-Clause 30.1, then the amount, determined by the Engineer, after due consultation with the Employer and the Contractor, to be due to such failure shall be recoverable from the Contractor by the Employer and may be deducted by the Employer from any monies due or to become due to the Contractor and the Engineer shall notify the Contractor accordingly, with a copy to the Employer. Provided also that the Employer shall notify the Contractor whenever a settlement is to be negotiated and, where any amount may be due from the Contractor, the Employer shall consult with the Contractor before such settlement is agreed. Where the nature of the Works is such as to require the use by the Contractor of waterborne transport the foregoing provisions of this Clause shall be construed as though “road” included a lock, dock, sea wall or other structure related to a waterway and “vehicle” included craft, and shall have effect accordingly. The Contractor shall, in accordance with the requirements of the Engineer, afford all reasonable opportunities for carrying out their work to: (a) any other contractors employed by the Employer and their workmen, (b) the workmen of the Employer, and (c) the workmen of any duly constituted authorities who may be employed in the execution on or near the Site of any work not included in the Contract or of any contract which the Employer may enter into in connection with or ancillary to the Works. If however, pursuant to Sub-Clause 31.1 the Contractor shall, on the written request of the Engineer: (a) make available to any such other contractor, or to the Employer or any such authority, any roads or ways for the maintenance of which the Contractor is responsible,  FIDIC 1987 14 (b) permit the use, by any such, of Temporary Works or Contractor’s Equipment on the Site, or (c) provide any other service of whatsoever nature for any such, the Engineer shall determine an addition to the Contract Price in accordance with Clause 52 and shall notify the Contractor accordingly, with a copy to the Employer. Labour Contractor to 32.1 Keep Site Clear Clearance of Site 33.1 on Completion Engagement of 34.1 Staff and Labour Returns of Labour 35.1 and Contractor’s Equipment During the execution of the Works the Contractor shall keep the Site reasonably free from all unnecessary obstruction and shall store or dispose of any Contractor’s Equipment and surplus materials and clear away and remove from the Site any wreckage, rubbish or Temporary Works no longer required. Upon the issue of any Taking-Over Certificate the Contractor shall clear away and remove from that part of the Site to which such Taking-Over Certificate relates all Contractor's Equipment, surplus material, rubbish and Temporary Works of every kind, and leave such part of the Site and Works clean and in a workmanlike condition to the satisfaction of the Engineer. Provided that the Contractor shall be entitled to retain on Site, until the end of the Defects Liability Period, such materials, Contractor’s Equipment and Temporary Works as are required by him for the purpose of fulfilling his obligations during the Defects Liability Period. The Contractor shall, unless otherwise provided in the Contract, make his own arrangements for the engagement of all staff and labour, local or other, and for their payment, housing, feeding and transport. The Contractor shall, if required by the Engineer, deliver to the Engineer a return in detail, in such form and at such intervals as the Engineer may prescribe, showing the staff and the numbers of the several classes of labour from time to time employed by the Contractor on the Site and such information respecting Contractor’s Equipment as the Engineer may require. Materials, Plant and Workmanship Quality of 36.1 Materials, Plant and Workmanship All materials, Plant and workmanship shall be: (a) of the respective kinds described in the Contract and in accordance with the Engineer’s instructions, and (b) subjected from time to time to such tests as the Engineer may require at the place of manufacture, fabrication or preparation, or on the Site or at such other place or places as may be specified in the Contract, or at all or any of such places. Cost of Samples 36.1 Cost of Tests 36.3 The Contractor shall provide such assistance. labour, electricity, fuels, stores, apparatus and instruments as are normally required for examining, measuring and testing any materials or Plant and shall supply samples of materials, before incorporation in the Works, for testing as may be selected and required by the Engineer. All samples shall be supplied by the Contractor at his own cost if the supply thereof is clearly intended by or provided for in the Contract. The cost of making any test shall be borne by the Contractor if such test is: (a) clearly intended by or provided for in the Contract, or (b) particularised in the Contract (in cases only of a test under load or of a test to ascertain whether the design of any finished or partially finished work is appropriate for the purposes which it was intended to fulfil) in sufficient detail to enable the Contractor to price or allow for the same in his Tender.  FIDIC 1987 15 Cost of Tests not 36.4 Provided for Engineer’s 36.5 Determination where Tests not Provided for Inspection of 37.1 Operations Inspection and 37.2 Testing Dates for 37.3 Inspection And Testing Rejection 37.4 If any test required by the Engineer which is: (a) not so intended by or provided for, (b) (in the cases above mentioned) not so particularised, or (c) (though so intended or provided for) required by the Engineer to be carried out at any place other than the Site or the place of manufacture, fabrication or preparation of the materials or Plant tested, shows the materials, Plant or workmanship not to be in accordance with the provisions of the Contract to the satisfaction of the Engineer, then the cost of such test shall be borne by the Contractor, but in any other case Sub-Clause 36.5 shall apply. Where, pursuant to Sub-Clause 36.4, this Sub-Clause applies the Engineer shall, after due consultation with the Employer and the Contractor, determine: (a) any extension of time to which the Contractor is entitled under Clause 44, and (b) the amount of such costs, which shall be added to the Contract Price, and shall notify the Contractor accordingly, with a copy to the Employer. The Engineer, and any person authorised by him, shall at all reasonable times have access to the Site and to all workshops and places where materials or Plant are being manufactured, fabricated or prepared for the Works and the Contractor shall afford every facility for and every assistance in obtaining the right to such access. The Engineer shall be entitled, during manufacture, fabrication or preparation to inspect and test the materials and Plant to be supplied under the Contract. If materials or Plant are being manufactured, fabricated or prepared in workshops or places other than those of the Contractor, the Contractor shall obtain permission for the Engineer to carry out such inspection and testing in those workshops or places. Such inspection or testing shall not release the Contractor from any obligation under the Contract. The Contractor shall agree with the Engineer on the time and place for the inspection or testing of any materials or Plant as provided in the Contract. The Engineer shall give the Contractor not less than 24 hours notice of his intention to carry out the inspection or to attend the tests. If the Engineer, or his duly authorised representative, does not attend on the date agreed, the Contractor may, unless otherwise instructed by the Engineer, proceed with the tests, which shall be deemed to have been made in the presence of the Engineer. The Contractor shall forthwith forward to the Engineer duly certified copies of the test readings. If the Engineer has not attended the tests, he shall accept the said readings as accurate. If, at the time and place agreed in accordance with Sub-Clause 37.3, the materials or Plant are not ready for inspection or testing or if, as a result of the inspection or testing referred to in this Clause, the Engineer determines that the materials or Plant are defective or otherwise not in accordance with the Contract, he may reject the materials or Plant and shall notify the Contractor thereof immediately. The notice shall state the Engineer's objections with reasons. The Contractor shall then promptly make good the defect or ensure that rejected materials or Plant comply with the Contract. If the Engineer so requests, the tests of rejected materials or Plant shall be made or repeated under the same terms and conditions. All costs incurred by the Employer by the repetition of the tests shall, after due consultation with the Employer and the Contractor, be determined by the Engineer and shall be recoverable from the Contractor by the Employer and may be deducted from any monies due or to become due to the Contractor and the Engineer shall notify the Contractor accordingly, with a copy to the Employer.  FIDIC 1987 16 Independent 37.5 Inspection Examination of 38.1 Work before Covering up Uncovering 38.2 and Making Openings Removal of 39.1 Improper Work, Materials or Plant Default of 39.2 Contractor in Compliance The Engineer may delegate inspection and testing of materials or Plant to an independent inspector. Any such delegation shall be effected in accordance with Sub-Clause 2.4 and for this purpose such independent inspector shall be considered as an assistant of the Engineer. Notice of such appointment (not being less than 14 days) shall be given by the Engineer to the Contractor. No part of the Works shall be covered up or put out of view without the approval of the Engineer and the Contractor shall afford full opportunity for the Engineer to examine and measure any such part of the Works which is about to be covered up or put out of view and to examine foundations before any part of the Works is placed thereon. The Contractor shall give notice to the Engineer whenever any such part of the Works or foundations is or are ready or about to be ready for examination and the Engineer shall, without unreasonable delay, unless he considers it unnecessary and advises the Contractor accordingly, attend for the purpose of examining and measuring such part of the Works or of examining such foundations. The Contractor shall uncover any part of the Works or make openings in or through the same as the Engineer may from time to time instruct and shall reinstate and make good such part. If any such part has been covered up or put out of view after compliance with the requirement of Sub-Clause 38.1 and is found to be executed in accordance with the Contract, the Engineer shall, after due consultation with the Employer and the Contractor, determine the amount of the Contractor’s costs in respect of such of uncovering, making openings in or through, reinstating and making good the same, which shall be added to the Contract Price, and shall notify the Contractor accordingly, with a copy to the Employer. In any other case all costs shall be borne by the Contractor. The Engineer shall have authority to issue instructions from time to time, for: (a) the removal from the Site, within such time or times as may be specified in the instruction, of any materials or Plant which, in the opinion of the Engineer, are not in accordance with the Contract, (b) the substitution of proper and suitable materials or Plant, and (c) the removal and proper re-execution, notwithstanding any previous test thereof or interim payment therefor, of any work which, in respect of (i) materials, Plant or workmanship, or (ii) design by the Contractor or for which he is responsible, is not, in the opinion of the Engineer, in accordance with the Contract. In case of default on the part of the Contractor in carrying out such instruction within the time specified therein or, if none, within a reasonable time, the Employer shall be entitled to employ and pay other persons to carry out the same and all costs consequent thereon or incidental thereto shall, after due consultation with the Employer and the Contractor, be determined by the Engineer and shall be recoverable from the Contractor by the Employer, and may be deducted by the Employer from any monies due or to become due to the Contractor and the Engineer shall notify the Contractor accordingly, with a copy to the Employer. Suspension Suspension 40. 1 of Work The Contractor shall, on the instructions of the Engineer, suspend the progress of he Works or any part thereof for such time and in such manner as the Engineer may consider necessary and shall, during such suspension, properly protect and secure the Works or such part thereof so far as is necessary in the opinion of the Engineer. Unless such suspension is: (a) otherwise provided for in the Contract, (b) necessary by reason of some default of or breach of contract by the Contractor or for which he is responsible,  FIDIC 1987 17 Engineer’s 40.2 Determination following Suspension, Suspension 40.3 lasting more than 84 Days (c) necessary by reason of climatic conditions on the Site, or (d) necessary for the proper execution of the Works or for the safety of the Works or any part thereof (save to the extent that such necessity arises from any act or default by the Engineer or the Employer or from any of the risks defined in Sub-Clause 20.4), Sub-Clause 40.2 shall apply. Where, pursuant to Sub-Clause 40.1, this Sub-Clause applies the Engineer shall after due consultation with the Employer and the Contractor, determine (a) any extension of time to which the Contractor is entitled under Clause 44, and (b) the amount, which shall be added to the Contract Price, in respect of the cost incurred by the Contractor by reason of such suspension, and shall notify the Contractor accordingly, with a copy to the Employer. If the progress of the Works or any part thereof is suspended on the instructions of the Engineer and if permission to resume work is not given by the Engineer within a period of 84 days from the date of suspension then, unless such suspension is within paragraph (a), (b), (c) or (d) of Sub-Clause 40.1, the Contractor may give notice to the Engineer requiring permission, within 28 days from the receipt thereof, to proceed with the Works or that part thereof in regard to which progress is suspended. If, within the said time, such permission is not granted, the Contractor may, but is not bound to, elect to treat the suspension, where it affects part only of the Works, as an omission of such part under Clause 51 by giving a further notice to the Engineer to that effect, or, where it affects the whole of the Works, treat the suspension as an event of default by the Employer and terminate his employment under the Contract in accordance with the provisions of Sub-Clause 69.1, whereupon the provisions of Sub-Clauses 69.2 and 69.3 shall apply. Commencement and Delays Commencement 41.1 of Works Possession of 42.1 Site and Access Thereto The Contractor shall commence the Works as soon as is reasonably possible after the receipt by him of a notice to this effect from the Engineer, which notice shall be issued within the time stated in the Appendix to fender after the date of the Letter of Acceptance. Thereafter, the Contractor shall proceed with the Works with due expedition and without delay. Save insofar as the Contract may prescribe: (a) the extent of portions of the Site of which the Contractor is to be given possession from time to time (b) the order in which such portions shall be made available to the Contractor, and, subject to any requirement in the Contract as to the order in which the Works shall be executed, the Employer will, with the Engineer's notice to commence the Works, give to the Contractor possession of (c) so much of the Site, and (d) such access as, in accordance with the Contract, is to be provided by the Employer as may be required to enable the Contractor to commence and proceed with the execution of the Works in accordance with the programme referred to in Clause 14, if any, and otherwise in accordance with such reasonable proposals as the Contractor shall, by notice to the Engineer with a copy to the Employer, make. The Employer will, from time to time as the Works proceed, give to the Contractor possession of such further portions of the Site as may be required to enable the Contractor to proceed with the execution of the Works with due dispatch in accordance with such programme or proposals, as the case may be.  FIDIC 1987 18 Failure to Give 42.2 Possession Rights of Way 42.3 and Facilities Contractor Time for 43.1 Completion Extension of Time 44.1 for Completion Contractor 44.2 to Provide Notification and Detailed Particulars Interim 44.3 Determination of Extension If the Contractor suffers delay and/or incurs costs from failure on the part of the Employer to give possession in accordance with the terms of Sub-Clause 42. 1, the Engineer shall, after due consultation with the Employer and the Contractor, determine: (a) any extension of time to which the Contractor is entitled under Clause 44, and (b) the amount of such costs, which shall be added to the Contract Price, and shall notify the Contractor accordingly, with a copy to the Employer. The Contractor shall bear all costs and charges for special or temporary rights of way required by him in connection with access to the Site. The shall also provide at his own cost any additional facilities outside the Site required by him for the purposes of the Works. The whole of the Works and, if applicable, any Section required to be completed within a particular time as stated in the Appendix to Tender, shall be completed in accordance with the provisions of Clause 48, within the time stated in the Appendix to Tender for the whole of the Works or the Section (as the case may be), calculated from the Commencement Date, or such extended time as may be allowed under Clause 44. In the event of: (a) the amount or nature of extra or additional work, (b) any cause of delay referred to in these Conditions, (c) exceptionally adverse climatic conditions, (d) any delay, impediment or prevention by the Employer, or (e) other special circumstances which may occur, other than through a default of or breach of contract by the Contractor or for which he is responsible, being such as fairly to entitle the Contractor to an extension of the Time for Completion of the Works, or any Section or part thereof, the Engineer shall, after due consultation with the Employer and the Contractor, determine the amount of such extension and shall notify the Contractor accordingly, with a copy to the Employer. Provided that the Engineer is not bound to make any determination unless the Contractor has (a) within 28 days after such event has first arisen notified the Engineer with a copy to the Employer, and (b) within 28 days, or such other reasonable time as may be agreed by the Engineer, after such notification submitted to the Engineer detailed particulars of any extension of time to which he may consider himself entitled in order that such submission may be investigated at the time. Provided also that where an event has a continuing effect such that it is not practicable for the Contractor to submit detailed particulars within the period of 28 days referred to in Sub-Clause 44.2(b), he shall nevertheless be entitled to an extension of time provided that he has submitted to the Engineer interim particulars at intervals of not more than 28 days and final particulars within 28 days of the end of the effects resulting from the event. On receipt of such interim particulars, the Engineer shall, without undue delay, make an interim determination of extension of time and, on receipt of the final particulars, the Engineer shall review all the circumstances and shall determine an overall extension of time in regard to the event. In both such cases the Engineer shall make his determination after due consultation with the Employer and the Contractor and shall notify the Contractor of the determination, with a copy to the Employer. No final review shall result in a decrease of any extension of time already determined by the Engineer.  FIDIC 1987 19 Restriction on 45.1 Working Hours Rate of Progress 46.1 Liquidated 47.1 Damages for Delay Reduction of 47.2 Liquidated Damages Subject to any provision to the contrary contained in the Contract, none of the Works shall, save as hereinafter provided, be carried on during the night or on locally recognised days of rest without the consent of the Engineer, except when work is unavoidable or absolutely necessary for the saving of life or property or for the safety of the Works, in which case the Contractor shall immediately advise the Engineer. Provided that the provisions of this Clause shall not be applicable in the case of any work which it is customary to carry out by multiple shifts. If for any reason, which does not entitle the Contractor to an extension of time, the rate of progress of the Works or any Section is at any time, in the opinion of the Engineer, too slow to comply with the Time for Completion, the Engineer shall so notify the Contractor who shall thereupon take such steps as are necessary, subject to the consent of the Engineer, to expedite progress so as to comply with the Time for Completion. The Contractor shall not be entitled to any additional payment for taking such steps. If, as a result of any notice given by the Engineer under this Clause, the Contractor considers that it is necessary to do any work at night or on locally recognised days of rest, he shall be entitled to seek the consent of the Engineer so to do. Provided that if any steps, taken by the Contractor in meeting his obligations under this Clause, involve the Employer in additional supervision costs, such costs shall, after due consultation with the Employer and the Contractor, be determined by the Engineer and shall be recoverable from the Contractor by the Employer, and may be deducted by the Employer from any monies due or to become due to the Contractor and the Engineer shall notify the Contractor accordingly, with a copy to the Employer. If the Contractor fails to comply with the Time for Completion in accordance with Clause 48, for the whole of the Works or, if applicable, any Section within the relevant time prescribed by Clause 43, then the Contractor shall pay to the Employer the relevant sum stated in the Appendix to Tender as liquidated damages for such default and not as a penalty (which sum shall be the only monies due from the Contractor for such default) for every day or part of a day which shall elapse between the relevant Time for Completion and the date stated in a Taking-Over Certificate of the whole of the Works or the relevant Section, subject to the applicable limit stated in the Appendix to Tender. The Employer may, without prejudice to any other method of recovery, deduct the amount of such damages from any monies due or to become due to the Contractor. The payment or deduction of such damages shall not relieve the Contractor from his obligation to complete the Works, or from any other of his obligations and liabilities under the Contract. If, before the Time for Completion of the whole of the Works or, if applicable, any Section, a Taking-Over Certificate has been issued for any part of the Works or of a Section, the liquidated damages for delay in completion of the remainder of the Works or of that Section shall, for any period of delay after the date stated in such Taking-Over Certificate, and in the absence of alternative provisions in the Contract, be reduced in the proportion which the value of the part so certified bears to the value of the whole of the Works or Section, as applicable. The provisions of this Sub-Clause shall only apply to the rate of liquidated damages and shall not affect the limit thereof.  FIDIC 1987 20 Taking-Over 48.1 Certificate Taking Over of 48.2 Sections or Parts Substantial 48.3 Completion of Parts Surfaces 48.4 Requiring Reinstatement When the whole of the Works have been substantially completed and have satisfactorily passed any Tests on Completion prescribed by the Contract, the Contractor may give a notice to that effect to the Engineer, with a copy to the Employer, accompanied by a written undertaking to finish with due expedition any outstanding work during the Defects Liability Period. Such notice and undertaking shall be deemed to be a request by the Contractor for the Engineer to issue a Taking-Over Certificate in respect of the Works. The Engineer shall, within 21 days of the date of delivery of such notice, either issue to the Contractor, with a copy to the Employer, a Taking-Over Certificate, stating the date on which, in his opinion, the Works were substantially completed in accordance with the Contract, or give instructions in writing to the Contractor specifying all the work which, in the Engineer's opinion, is required to be done by the Contractor before the issue of such Certificate. The Engineer shall also notify the Contractor of any defects in the Works affecting substantial completion that may appear after such instructions and before completion of -Over Certificate within 21 days of completion, to the satisfaction of the Engineer, of the Works so specified and remedying any defects so notified. Similarly, in accordance with the procedure set out in Sub-Clause 48.1, the Contractor may request and the Engineer shall issue a Taking-Over Certificate in respect of: (a) any Section in respect of which a separate Time for Completion is provided in the Appendix to Tender, (b) any substantial part of the Permanent Works which has been both completed to the satisfaction of the Engineer and, otherwise than as provided for in the Contract, occupied or used by the Employer, or (c) any part of the Permanent Works which the Employer has elected to occupy or use prior to completion (where such prior occupation or use is not provided for in the Contract or has not been agreed by the Contractor as a temporary measure). If any part of the Permanent Works has been substantially completed and has satisfactorily passed any Tests on Completion prescribed by the Contract, the Engineer may issue a Taking-Over Certificate in respect of that part of the Permanent Works before completion of the whole of the Works and, upon the issue of such Certificate, the Contractor shall be deemed to have undertaken to complete with due expedition any outstanding work in that part of the Permanent Works during the Defects Liability Period. Provided that a Taking-Over Certificate given in respect of any Section or part of the Permanent Works before completion of the whole of the Works shall not be deemed to certify completion of any ground or surfaces requiring reinstatement, unless such Taking-Over Certificate shall expressly so state. Defects Liability Defects Liability 49.1 Period In these Conditions the expression “Defects Liability Period” shall mean the defects liability period named in the Appendix to Tender, calculated from: (a) the date of completion of the Works certified by the Engineer in accordance with Clause 48, or (b) in the event of more than one certificate having been issued by the Engineer under Clause 48, the respective dates so certified, and in relation to the Defects Liability Period the expression “the Works” shall be construed accordingly.  FIDIC 1987 21 Completion of 49.2 Outstanding Work and Remedying Defects Cost of 49.3 Remedying Defects Contractor’s 49.4 Failure to Carry Out Instructions Contractor 50.1 to Search To the intent that the Works shall, at or as soon as practicable after the expiration of the Defects Liability Period, be delivered to the Employer in the condition required by the Contract, fair wear and tear excepted, to the satisfaction of the Engineer, the Contractor shall: (a) complete the work, if any, outstanding on the date stated in the Taking-Over Certificate as soon as practicable after such date, and (b) execute all such work of amendment, reconstruction, and remedying defects, shrinkages or other faults as the Engineer may, during the Defects Liability Period or within 14 days after its expiration, as a result of an inspection made by or on behalf of the Engineer prior to its expiration, instruct the Contractor to execute. All work referred to in Sub-Clause 49.2 (b) shall be executed by the Contractor at his own cost if the necessity thereof is, in the opinion of the Engineer, due to: (a) the use of materials, Plant or workmanship not in accordance with the Contract, (b) where the Contractor is responsible for the design of part of the Permanent Works, any fault in such design, or (c) he neglect or failure on the part of the Contractor to comply with any obligation, expressed or implied, on the Contractor’s part under the Contract. If, in the opinion of the Engineer, such necessity is due to any other cause, he shall determine an addition to the Contract Price in accordance with Clause 52 and shall notify the Contractor accordingly, with a copy to the Employer. In case of default on the part of the Contractor in carrying out such instruction within a reasonable time, the Employer shall be entitled to employ and pay other persons to carry out the same and if such work is work which, in the opinion of the Engineer, the Contractor was liable to do at his own cost under the Contract, then all costs consequent thereon or incidental thereto shall, after due consultation with the Employer and the Contractor, be determined by the Engineer and shall be recoverable from the Contractor by the Employer, and may be deducted by the Employer from any monies due or to become due to the Contractor and the Engineer shall notify the Contractor accordingly, with a copy to the Employer. If any defect, shrinkage or other fault in the Works appears at any time prior to the end of the Defects Liability Period, the Engineer may instruct the Contractor, with copy to the Employer, to search under the directions of the Engineer for the cause thereof. Unless such defect, shrinkage or other fault is one for which the Contractor is liable under the Contract, the Engineer shall, after due consultation with the Employer and the Contractor, determine the amount in respect of the costs of such search incurred by the Contractor, which shall be added to the Contract Price and shall notify the Contractor accordingly, with a copy to the Employer. If such defect, shrinkage or other fault is one for which the Contractor is liable, the cost of the work carried out in searching as aforesaid shall be borne by the Contractor and he shall in such case remedy such defect, shrinkage or other fault at his own cost in accordance with the provisions of Clause 49. Alterations, Additions and Omissions Variations 51.1 The Engineer shall make any variation of the form, quality or quantity of the Works or any part thereof that may, in his opinion, be necessary and for that purpose, or if for any other reason it shall, in his opinion, be appropriate, he shall have the authority to instruct the Contractor to do and the Contractor shall do any of the following: (a) increase or decrease the quantity of any work included in the Contract, (b) omit any such work (but not if the omitted work is to be carried out by the (c) Employer or by another contractor),  FIDIC 1987 22 Instructions for 51.2 Variations Valuation of 52.1 Variations Power 52.2 of Engineer to Fix Rates Variations 52.3 Exceeding 15 per cent (d) change the character or quality or kind of any such work, (e) change the levels, lines, position and dimensions of any part of the Works, (f) execute additional work of any kind necessary for the completion of the Works, or (g) change any specified sequence or timing of construction of any part of the Works. No such variation shall in any way vitiate or invalidate the Contract, but the effect, if any, of all such variations shall be valued in accordance with Clause 52. Provided that where the issue of an instruction to vary the Works is necessitated by some default of or breach of contract by the Contractor or for which he is responsible, any additional cost attributable to such default shall be borne by the Contractor. The Contractor shall not make any such variation without an instruction of the Engineer. Provided that no instruction shall be required for increase or decrease in the quantity of any work where such increase or decrease is not the result of an instruction given under this Clause, but is the result of the quantities exceeding or being less than those stated in the Bill of Quantities. All variations referred to in Clause 51 and any additions to the Contract Price which are required to be determined in accordance with Clause 52 (for the purposes of this Clause referred to as “varied work”), shall be valued at the rates and prices set out in the Contract if, in the opinion of the Engineer, the same shall be applicable. If the Contract does not contain any rates or prices applicable to the varied work, the rates and prices in the Contract shall be used as the basis for valuation so far as may be reasonable, failing which, after due consultation by the Engineer with the Employer and the Contractor, suitable rates or prices shall be agreed upon between the Engineer and the Contractor. In the event of disagreement the Engineer shall fix such rates or prices as are, in his opinion, appropriate and shall notify the Contractor accordingly, with a copy to the Employer. Until such time as rates or prices are agreed or fixed, the Engineer shall determine provisional rates or prices to enable on-account payments to be included in certificates issued in accordance with Clause 60. Provided that if the nature or amount of any varied work relative to the nature or amount of the whole of the Works or to any part thereof, is such that, in the opinion of the Engineer, the rate or price contained in the Contract for any item of the Works is, by reason of such varied work, rendered inappropriate or inapplicable, then, after due consultation by the Engineer with the Employer and the Contractor, a suitable rate or price shall be agreed upon between the Engineer and the Contractor. In the event of disagreement the Engineer shall fix such other rate or price as is, in his opinion, appropriate and shall notify the Contractor accordingly, with a copy to the Employer. Until such time as rates or prices are agreed or fixed, the Engineer shall determine provisional rates or prices to enable on-account payments to be included in certificates issued in accordance with Clause 60. Provided also that no varied work instructed to be done by the Engineer pursuant to Clause 51 shall be valued under Sub-Clause 52.1 or under this Sub-Clause unless, within 14 days of the date of such instruction and, other than in the case of omitted work, before the commencement of the varied work, notice shall have been given either: (a) by the Contractor to the Engineer of his intention to claim extra payment or a varied rate or price, or (b) by the Engineer to the Contractor of his intention to vary a rate or a price If, on the issue of the Taking-Over Certificate for the whole of the Works, it is found that as a result of: (a) all varied work valued under Sub-Clauses 52.1 and 52.2, and  FIDIC 1987 23 Daywork 52.4 (b) all adjustments upon measurement of the estimated quantities set out in the Bill of Quantities, excluding Provisional Sums, dayworks and adjustments of price made under Clause 70, but not from any other cause, there have been additions to or deductions from the Contract Price which taken together are in excess of 15 per cent of the “Effective Contract Price” (which for the purposes of this Sub-Clause shall mean the Contract Price, excluding Provisional Sums and allowance for dayworks, if any) then and in such event (subject to any action already taken under any other Sub-Clause of this Clause), after due consultation by the Engineer with the Employer and the Contractor, there shall be added to or deducted from the Contract Price such further sum as may be agreed between the Contractor and the Engineer or, failing agreement, determined by the Engineer having regard to the Contractor’s Site and general overhead costs of the Contract. The Engineer shall notify the Contractor of any determination made under this Sub-Clause, with a copy to the Employer. Such sum shall be based only on the amount by which such additions or deductions shall be in excess of 15 per cent of the Effective Contract Price. The Engineer may, if in his opinion it is necessary or desirable, issue an instruction that any varied work shall be executed on a daywork basis. The Contractor shall then be paid for such varied work under the terms set out in the daywork schedule included in the Contract and at the rates and prices affixed thereto by him in the Tender. The Contractor shall furnish to the Engineer such receipts or other vouchers as may be necessary to prove the amounts paid and, before ordering materials, shall submit to the Engineer quotations for the same for his approval. In respect of such of the Works executed on a daywork basis, the Contractor shall, during the continuance of such work, deliver each day to the Engineer an exact list in duplicate of the names, occupation and time of all workmen employed on such work and a statement, also in duplicate, showing the description and quantity of all materials and Contractor's Equipment used thereon or therefor other than Contractor's Equipment which is included in the percentage addition in accordance with such daywork schedule. One copy of each list and statement will, if correct, or when agreed, be signed by the Engineer and returned to the Contractor. At the end of each month the Contractor shall deliver to the Engineer a priced statement of the labour, materials and Contractor's Equipment, except as aforesaid, used and the Contractor shall not be entitled to any payment unless such lists and statements have been fully and punctually rendered. Provided always that if the Engineer considers that for any reason the sending of such lists or statements by the Contractor, in accordance with the foregoing provision, was impracticable he shall nevertheless be entitled to authorise payment for such work, either as daywork, on being satisfied as to the time employed and the labour, materials and Contractor's Equipment used on such work, or at such value therefor as shall, in his opinion, be fair and reasonable. Procedure for Claims Notice of Claims 53.1 Contemporary 53.2 Records Notwithstanding any other provision of the Contract, if the Contractor intends to claim any additional payment pursuant to any Clause of these Conditions or otherwise, he shall give notice of his intention to the Engineer, with a copy to the Employer, within 28 days after the event giving rise to the claim has first arisen. Upon the happening of the event referred to in Sub-Clause 53.1, the Contractor shall keep such contemporary records as may reasonably be necessary to support any claim he may subsequently wish to make. Without necessarily admitting the Employer's liability, the Engineer shall, on receipt of a notice under Sub-Clause 53.1, inspect such contemporary records and may instruct the Contractor to keep  FIDIC 1987 24 Substantiation 53.3 of Claims Failure to Comply 53.4 Payment of Claims 53.5 any further contemporary records as are reasonable and may be material to the claim of which notice has been given. The Contractor shall permit the Engineer to inspect all records kept pursuant to this Sub-Clause and shall supply him with copies thereof as and when the Engineer so instructs. Within 28 days, or such other reasonable time as may be agreed by the Engineer, of giving notice under Sub-Clause 53.1, the Contractor shall send to the Engineer an account giving detailed particulars of the amount claimed and the grounds upon which the claim is based. Where the event giving rise to the claim has a continuing effect, such account shall be considered to be an interim account and the Contractor shall, at such intervals as the Engineer may reasonably require, send further interim accounts giving the accumulated amount of the claim and any further grounds upon which it is based. In cases where interim accounts are sent to the Engineer, the Contractor shall send a final account within 28 days of the end of the effects resulting from the event. The Contractor shall, if required by the Engineer so to do, copy to the Employer all accounts sent to the Engineer pursuant to this Sub-Clause. If the Contractor fails to comply with any of the provisions of this Clause in respect of any claim which he seeks to make, his entitlement to payment in respect thereof shall not exceed such amount as the Engineer or any arbitrator or arbitrators appointed pursuant to Sub-Clause 67.3 assessing the claim considers to be verified by contemporary records (whether or not such records were brought to the Engineer's notice as required under Sub-Clauses 53.2 and 53.3). The Contractor shall be entitled to have included in any interim payment certified by the Engineer pursuant to Clause 60 such amount in respect of any claim as the Engineer, after due consultation with the Employer and the Contractor, may consider due to the Contractor provided that the Contractor has supplied sufficient particulars to enable the Engineer to determine the amount due. If such particulars are insufficient to substantiate the whole of the claim, the Contractor shall be entitled to payment in respect of such part of the claim as such particulars may substantiate to the satisfaction of the Engineer. The Engineer shall notify the Contractor of any determination made under this Sub-Clause, with a copy to the Employer. Contractor’s Equipment, Temporary Works and Materials Contractor’s 54.1 Equipment, Temporary Works and Materials; Exclusive Use for the Works Employer not 54.2 Liable for Damage Customs 54.3 Clearance Re-export of 54.4 Contractor’s Equipment All Contractor’s Equipment, Temporary Works and materials provided by the Contractor shall, when brought on to the Site, be deemed to be exclusively intended for the execution of the Works and the Contractor shall not remove the same or any part thereof, except for the purpose of moving it from one part of the Site to another, without the consent of the Engineer. Provided that consent shall not be required for vehicles engaged in transporting any staff, labour, Contractor’s Equipment, Temporary Works, Plant or materials to or from the Site. The Employer shall not at any time be liable, save as mentioned in Clauses 20 and 65, for the loss of or damage to any of the said Contractor's Equipment, Temporary Works or materials. The Employer will use his best endeavours in assisting the Contractor, where required, in obtaining clearance through the Customs of Contractor's Equipment, materials and other things required for the Works. In respect of any Contractor’s Equipment which the Contractor has imported for the purposes of the Works, the Employer will use his best endeavours to assist the Contractor, where required, in procuring any necessary Government consent to the re-export of such Contractor’s Equipment by the Contractor upon the removal thereof pursuant to the terms of the Contract.  FIDIC 1987 25 Conditions of Hire 54.5 of Contractor’s Equipment Costs for the 54.6 Purpose of Clause 63 Incorporation of 54.7 Clause in Subcontracts Approval of 54.8 Materials not Implied With a view to securing, in the event of termination under Clause 63, the continued availability, for the purpose of executing the Works, of any hired Contractor’s Equipment, the Contractor shall not bring on to the Site any hired Contractor’s Equipment unless there is an agreement for the hire thereof (which agreement shall be deemed not to include an agreement for hire purchase) which contains a provision that the owner thereof will, on request in writing made by the Employer within 7 days after the date on which any termination has become effective, and on the Employer undertaking to pay all hire charges in respect thereof from such date, hire such Contractor’s Equipment to the Employer on the same terms in all respects as the same was hired to the Contractor save that the Employer shall be entitled to permit the use thereof by any other contractor employed by him for the purpose of executing and completing the Works and remedying any defects therein, under the terms of the said Clause 63. In the event of the Employer entering into any agreement for the hire of Contractor’s Equipment pursuant to Sub-Clause 54.5, all sums properly paid by the Employer under the provisions of any such agreement and all costs incurred by him (including stamp duties) in entering into such agreement shall be deemed, for the purpose of Clause 63, to be part of the cost of executing and completing the Works and the remedying of any defects therein. The Contractor shall, where entering into any subcontract for the execution of any part of the Works, incorporate in such subcontract (by reference or otherwise) the provisions of this Clause in relation to Contractor's Equipment, Temporary Works or materials brought on to the Site by the Subcontractor. The operation of this Clause shall not be deemed to imply any approval by the Engineer of the materials or other matters referred to therein nor shall it prevent he rejection of any such materials at any time by the Engineer. Measurement Quantities 55.1 Work to be 56.1 Measured The quantities set out in the Bill of Quantities are the estimated quantities for the Works, and they are not to be taken as the actual and correct quantities of the Works to be executed by the Contractor in fulfilment of his obligations under the Contract. The Engineer, shall except as otherwise stated, ascertain and determine by measurement the value of the Works in accordance with the Contract and the Contractor shall be paid that value in accordance with Clause 60. The Engineer shall, when he requires any part of the Works to be measured, give reasonable notice to the Contractor’s authorised agent, who shall: (a) forthwith attend or send a qualified representative to assist the Engineer in making such measurement, and (b) supply all particulars required by the Engineer. should the Contractor not attend, or neglect or omit to send such representative, then the measurement made by the Engineer or approved by him shall be taken to be the correct measurement of such part of the Works. For the purpose of measuring such Permanent Works as are to be measured by records and drawings, the Engineer shall prepare records and drawings as the work proceeds and the Contractor, as and when called upon to do so in writing, shall, within 14 days, attend to examine and agree such records and drawings with the Engineer and shall sign the same when so agreed. If the Contractor does not attend to examine and agree such records and drawings, they shall be taken to be correct. If, after examination of such records and drawings, the Contractor does not agree the same or does not sign the same as agreed, they shall nevertheless be taken to be correct, unless the Contractor, within 14 days of such examination, lodges with the Engineer notice of the respects in which such records and drawings are claimed by him to be incorrect. On receipt of such notice, the Engineer shall review the records and drawings and either confirm or vary them.  FIDIC 1987 26 Method of 57.1 Measurement Breakdown of 57.2 Lump Sum Items The Works shall be measured net, notwithstanding any general or local custom, except where otherwise provided for in the Contract. For the purposes of statements submitted in accordance with Sub-Clause 60.1, the Contractor shall submit to the Engineer, within 28 days after the receipt of the Letter of Acceptance, a breakdown for each of the lump sum items contained in the Tender. Such breakdowns shall be subject to the approval of the Engineer. Provisional Sums Definition of 58.1 “Provisional Sum” Use of 58.2 Provisional Sums Production of 58.3 Vouchers “Provisional Sum” means a sum included in the Contract and so designated in the Bill of Quantities for the execution of any part of the Works or for the supply of goods, materials, Plant or services, or for contingencies, which sum may be used, in whole or in part, or not at all, on the instructions of the Engineer. The Contractor shall be entitled to only such amounts in respect of the work, supply or contingencies to which such Provisional Sums relate as the Engineer shall determine in accordance with this Clause. The Engineer shall notify the Contractor of any determination made under this Sub-Clause, with a copy to the Employer. In respect of every Provisional Sum the Engineer shall have authority to issue instructions for the execution of work or for the supply of goods, materials, Plant or services by: (a) the Contractor, in which case the Contractor shall be entitled to an amount equal to the value thereof determined in accordance with Clause 52, and (b) a nominated Subcontractor, as hereinafter defined, in which case the sum to be paid to the Contractor therefore shall be determined and paid in accordance with Sub-Clause 59.4. The Contractor shall produce to the Engineer all quotations, invoices, vouchers and accounts or receipts in connection with expenditure in respect of Provisional Sums, except where work is valued in accordance with rates or prices set out in the Tender. Nominated Subcontractors Definition of 59.1 “Nominated Subcontractors” Nominated 59.2 Subcontractors; Objection to Nomination All specialists, merchants, tradesmen and others executing any work or supplying any goods, materials, Plant or services for which Provisional Sums are included in the Contract, who may have been or be nominated or selected or approved by the Employer or the Engineer, and all persons to whom by virtue of the provisions of the Contract the Contractor is required to subcontract shall, in the execution of such work or the supply of such goods, materials, Plant or services, be deemed to be subcontractors to the Contractor and are referred to in this Contract as “nominated Subcontractors”. The Contractor shall not be required by the Employer or the Engineer, or be deemed to be under any obligation, to employ any nominated Subcontractor against whom the Contractor may raise reasonable objection, or who declines to enter into a subcontract with the Contractor containing provisions: (a) that in respect of the work, goods, materials, Plant or services the subject of the subcontract, the nominated Subcontractor will undertake towards the Contractor such obligations and liabilities as will enable the Contractor to discharge his own obligations and liabilities towards the Employer under the terms of the Contract and will save harmless and indemnify the Contractor from and against the same and from all claims, proceedings, damages, costs, charges and expenses whatsoever arising out of or in connection therewith, or arising out of or in connection with any failure to perform such obligations or to fulfil such liabilities, and  FIDIC 1987 27 Design 59.3 Requirements to be Expressly Stated Payments to 59.4 Nominated Subcontractors Certification of 59.5 Payments to Nominated Subcontractors (b) that the nominated Subcontractor will save harmless and indemnify the Contractor from and against any negligence by the nominated Subcontractor, his agents, workmen and servants and from and against any misuse by him or them of any Temporary Works provided by the Contractor for the purposes of the Contract and from all claims as aforesaid. If in connection with any Provisional Sum the services to be provided include any matter of design or specification of any part of the Permanent Works or of any Plant to be incorporated therein, such requirement shall be expressly stated in the Contract and shall be included in any nominated Subcontract. The nominated Subcontract shall specify that the nominated Subcontractor providing such services will save harmless and indemnify the Contractor from and against the same and from all claims, proceedings, damages, costs, charges and expenses whatsoever arising out of or in connection with any failure to perform such obligations or to fulfil such liabilities. For all work executed or goods, materials, Plant or services supplied by any nominated Subcontractor, the Contractor shall be entitled to: (a) the actual price paid or due to be paid by the Contractor, on the instructions of the Engineer, and in accordance with the subcontract; (b) in respect of labour supplied by the Contractor, the sum, if any, entered in the Bill of Quantities or, if instructed by the Engineer pursuant to paragraph (a) of Sub-Clause 58.2, as may be determined in accordance with Clause 52; and (c) in respect of all other charges and profit, a sum being a percentage rate of the actual price paid or due to be paid calculated, where provision has been made in the Bill of Quantities for a rate to be set against the relevant Provisional Sum, at the rate inserted by the Contractor against that item or, where no such provision has been made, at the rate inserted by the Contractor in the Appendix to Tender and repeated where provision for such is made in a special item provided in the Bill of Quantities for such purpose. Before issuing, under Clause 60, any certificate, which includes any payment in respect of work done or goods, materials, Plant or services supplied by any nominated Subcontractor, the Engineer shall be entitled to demand from the Contractor reasonable proof that all payments, less retentions, included in previous certificates in respect of the work or goods, materials, Plant or services of such nominated Subcontractor have been paid or discharged by the Contractor. If the Contractor fails to supply such proof then, unless the Contractor: (a) satisfies the Engineer in writing that he has reasonable cause for withholding or refusing to make such payments, and (b) produces to the Engineer reasonable proof that he has so informed such nominated Subcontractor in writing, the Employer shall be entitled to pay to such nominated Subcontractor direct, upon the certificate of the Engineer, all payments, less retentions, provided for in the nominated Subcontract, which the Contractor has failed to make to such nominated Subcontractor and to deduct by way of set-off the amount so paid by the Employer from any sums due or to become due from the Employer to the Contractor. Provided that, where the Engineer has certified and the Employer has paid direct as aforesaid, the Engineer shall, in issuing any further certificate in favour of the Contractor, deduct from the amount thereof the amount so paid, direct as aforesaid, but shall not withhold or delay the issue of the certificate itself when due to be issued under the terms of the Contract.  FIDIC 1987 28 Certificates and Payment Monthly 60.1 Statements The Contractor shall submit to the Engineer after the end of each month six copies, each signed by the Contractor’s representative approved by the Engineer in accordance with Sub-Clause 15.1, of a statement, in such form as the Engineer may from time to time prescribe, showing the amounts to which the Contractor considers himself to be entitled up to the end of the month in respect of: (a) the value of the Permanent Works executed, (b) any other items in the Bill of Quantities including those for Contractor’s Equipment, Temporary Works, dayworks and the like, (c) the percentage of the invoice value of listed materials, all as stated in the Appendix to Tender, and Plant delivered by the Contractor on the Site for incorporation in the Permanent Works but not incorporated in such Works, (d) adjustments under Clause 70, and Monthly Payments 60.2 Payment of 60.3 Retention Money Correction of 60.4 Certificates (e) any other sum to which the Contractor may be entitled under the Contract or otherwise. The Engineer shall, within 28 days of receiving such statement, deliver to the Employer an Interim Payment Certificate stating the amount of payment to the Contractor which the Engineer considers due and payable in respect of such statement, subject: (a) firstly, to the retention of the amount calculated by applying the Percentage of Retention stated in the Appendix to Tender, to the amount to which the Contractor is entitled under paragraphs (a), (b), (c) and (e) of Sub-Clause 60.1 until the amount so retained reaches the Limit of Retention Money stated in the Appendix to Tender, and (b) secondly, to the deduction, other than pursuant to Clause 47, of any sums which may have become due and payable by the Contractor to the Employer. Provided that the Engineer shall not be bound to certify any payment under this Sub-Clause if the net amount thereof, after all retentions and deductions, would be less than the Minimum Amount of Interim Payment Certificates stated in the Appendix to Tender. Notwithstanding the terms of this Clause or any other Clause of the Contract no amount will be certified by the Engineer for payment until the performance security, if required under the Contract, has been provided by the Contractor and approved by the Employer. (a) Upon the issue of the Taking-Over Certificate with respect to the whole of the Works, one half of the Retention Money, or upon the issue of a Taking-Over Certificate with respect to a Section or part of the Permanent Works only such proportion thereof as the Engineer determines having regard to the relative value of such Section or part of the Permanent Works, shall be certified by the Engineer for payment to the Contractor. (b) Upon the expiration of the Defects Liability Period for the Works the other half of the Retention Money shall be certified by the Engineer for payment to the Contractor. Provided that, in the event of different Defects Liability Periods having become applicable to different Sections or parts of the Permanent Works pursuant to Clause 48, the expression "expiration of the Defects Liability Period" shall, for the purposes of this Sub-Clause, be deemed to mean the expiration of the latest of such periods. Provided also that if at such time there shall remain to be executed by the Contractor any work instructed, pursuant to Clauses 49 and 50, in respect of the Works, the Engineer shall be entitled to withhold certification until completion of such work of so much of the balance of the Retention Money as shall, in the opinion of the Engineer, represent the cost of the work remaining to be executed. The Engineer may by any Interim Payment Certificate make any correction or modification in any previous Interim Payment Certificate which shall have been issued by him and shall have authority, if any work is not being carried out to his satisfaction, to omit or reduce the value of such work in any Interim Payment Certificate.  FIDIC 1987 29 Statement at 60.5 Completion Final Statement 60.6 Discharge 60.7 Final Payment 60.8 Certificate Cessation of 60.9 Employer’s Liability Not later than 84 days after the issue of the Taking-Over Certificate in respect of the whole of the Works, the Contractor shall submit to the Engineer six copies of Statement at Completion with supporting documents showing in detail, in the form approved by the Engineer: (a) the final value of all work done in accordance with the Contract up to the date stated in such Taking-Over Certificate, (b) any further sums which the Contractor considers to be due, and (c) an estimate of amounts which the Contractor considers will become due to him under the Contract. The estimated amounts shall be shown separately in such Statement at Completion. The Engineer shall certify payment in accordance with Sub-Clause 60.2. Not later than 56 days after the issue of the Defects Liability Certificate pursuant to Sub-Clause 62. 1, the Contractor shall submit to the Engineer for consideration six copies of a draft final statement with supporting documents showing in detail, in the form approved by the Engineer: (a) the value of all work done in accordance with the Contract, and (b) any further sums which the Contractor considers to be due to him under the Contract or otherwise. If the Engineer disagrees with or cannot verify any part of the draft final statement, the Contractor shall submit such further information as the Engineer may reasonably require and shall make such changes in the draft as may be agreed between them. The Contractor shall then prepare and submit to the Engineer the final statement as agreed (for the purposes of these Conditions referred to as the “Final Statement”). If, following discussions between the Engineer and the Contractor and any changes to he draft final statement which may be agreed between them, it becomes evident that a dispute exists, the Engineer shall deliver to the Employer an Interim Payment Certificate for those parts of the draft final statement, if any, which are not in dispute. The dispute may then be settled in accordance with Clause 67. Upon submission of the Final Statement, the Contractor shall give to the Employer, with a copy to the Engineer, a written discharge confirming that the total of the Final Statement represents full and final settlement of all monies due to the Contractor arising out of or in respect of the Contract. Provided that such discharge shall become effective only after payment due under the Final Payment Certificate issued pursuant to Sub-Clause 60.8 has been made and the performance security referred to in Sub-Clause 10.1, if any, has been returned to the Contractor. Within 28 days after receipt of the Final Statement, and the written discharge, the Engineer shall issue to the Employer (with a copy to the Contractor) a Final Payment Certificate stating: (a) the amount which, in the opinion of the Engineer, is finally due under the Contract or otherwise, and (b) after giving credit to the Employer for all amounts previously paid by the Employer and for all sums to which the Employer is entitled other than under Clause 47, the balance, if any, due from the Employer to the Contractor or from the Contractor to the Employer as the case may be. The Employer shall not be liable to the Contractor for any matter or thing arising out of or in connection with the Contract or execution of the Works, unless the Contractor shall have included a claim in respect thereof in his Final Statement and (except in respect of matters or things arising after the issue of the Taking-Over Certificate in respect of the whole of the Works) in the Statement at Completion referred to in Sub-Clause 60.5.  FIDIC 1987 30 Time for Payment 60.10 Approval only by 61.1 Defects Liability Certificate Defects Liability 62.1 Certificate Unfulfilled 62.2 Obligations The amount due to the Contractor under any Interim Payment Certificate issued by the Engineer pursuant to this Clause, or to any other term of the Contract, shall, subject to Clause 47, be paid by the Employer to the Contractor within 28 days after such Interim Payment Certificate has been delivered to the Employer, or, in the case of the Final Payment Certificate referred to in Sub-Clause 60.8, within 56 days, after such Final Payment Certificate has been delivered to the Employer. In the event of the failure of the Employer to make payment within the times stated, the Employer shall pay to the Contractor interest at the rate stated in the Appendix to Tender upon all sums unpaid from the date by which the same should have been paid. The provisions of this Sub-Clause are without prejudice to the Contractor's entitlement under Clause 69 or otherwise. Only the Defects Liability Certificate, referred to in Clause 62, shall be deemed to constitute approval of the Works. The Contract shall not be considered as completed until a Defects Liability Certificate shall have been signed by the Engineer and delivered to the Employer, with a copy to, the Contractor, stating the date on which the Contractor shall have completed his obligations to execute and complete the Works and remedy any defects therein to the Engineer’s satisfaction. The Defects Liability Certificate shall be given by the Engineer within 28 days after the expiration of the Defects Liability Period, or, if different defects liability periods shall become applicable to different Sections or parts of the Permanent Works, the expiration of the latest such period, or as soon thereafter as any works instructed, pursuant to Clauses 49 and 50, have been completed to the satisfaction of the Engineer. Provided that the issue of the Defects Liability Certificate shall not be a condition precedent to payment to the Contractor of the second portion of the Retention Money in accordance with the conditions set out in Sub-Clause 60.3. Notwithstanding the issue of the Defects Liability Certificate the Contractor and the Employer shall remain liable for the fulfilment of any obligation incurred under the provisions of the Contract prior to the issue of the Defects Liability Certificate which remains unperformed at the time such Defects Liability Certificate is issued and, for the purposes of determining the nature and extent of any such obligation, the Contract shall be deemed to remain in force between the parties to the Contract. Remedies Default of 63.1 Contractor If the Contractor is deemed by law unable to pay his debts as they fall due, or enters into voluntary or involuntary bankruptcy, liquidation or dissolution (other than a voluntary liquidation for the purposes of amalgamation or reconstruction), or becomes insolvent, or makes an arrangement with. or assignment in favour of, his creditors, or agrees to carry out the Contract under a committee of inspection of his creditors, or if a receiver, administrator, trustee or liquidator is appointed over any substantial part of his assets, or if, under any law or regulation relating to reorganization, arrangement or readjustment of debts, proceedings are commenced against the Contractor or resolutions passed in connection with dissolution or liquidation or if any steps are taken to enforce any security interest over a substantial part of the assets of the Contractor, or if any act is done or event occurs with respect to the Contractor or his assets which, under any applicable law has a substantially similar effect to any of the foregoing acts or events, or if the Contractor has contravened SubClause 3. 1, or has an execution levied on his goods, or if the Engineer certifies to the Employer, with a copy to the Contractor, that, in his opinion, the Contractor: (a) has repudiated the Contract, (b) without reasonable excuse has failed (i) to commence the Works in accordance with Sub-Clause 4 1. 1, or (ii) to proceed with the Works, or any Section thereof, within 28 days after receiving notice pursuant to Sub-Clause 46. 1,  FIDIC 1987 31 Valuation at Date 63.2 of Termination Payment after 63.3 Termination Assignment of 63.4 Benefit of Agreement Urgent Remedial 64.1 Work (c) has failed to comply with a notice issued pursuant to Sub-Clause 37.4 or an instruction issued pursuant to Sub-Clause 39.1 within 28 days after having received it, (d) despite previous warning from the Engineer, in writing, is otherwise persistently or flagrantly neglecting to comply with any of his obligations under the Contract, or (e) has contravened Sub-Clause 4.1, then the Employer may, after giving 14 days’ notice to the Contractor, enter upon the Site and the Works and terminate the employment of the Contractor without thereby releasing the Contractor from any of his obligations or liabilities under the Contract, or affecting the rights and authorities conferred on the Employer or the Engineer by the Contract, and may himself complete the Works or may employ any other contractor to complete the Works. The Employer or such other contractor may use for such completion so much of the Contractor’s Equipment, Temporary Works and materials as he or they may think proper. The Engineer shall, as soon as may be practicable after any such entry and termination by the Employer, fix and determine ex parte, or by or after reference to the parties or after such investigation or enquiries as he may think fit to make or institute, and shall certify: (a) what amount (if any) had, at the time of such entry and termination, been reasonably earned by or would reasonably accrue to the Contractor in respect of work then actually done by him under the Contract, and (b) the value of any of the said unused or partially used materials, any Contractor’s Equipment and any Temporary Works. If the Employer terminates the Contractor’s employment under this Clause, he shall not be liable to pay to the Contractor any further amount (including damages) in respect of the Contract until the expiration of the Defects Liability Period and there after until the costs of execution, completion and remedying of any defects, damages for delay in completion (if any) and all other expenses incurred by the Employer have been ascertained and the amount thereof certified by the Engineer. The Contractor shall then be entitled to receive only such sum (if any) as the Engineer may certify would have been payable to him upon due completion by him after deducting the said amount. If such amount exceeds the sum which would have been payable to the Contractor on due completion by him, then the Contractor shall, upon demand, pay to the Employer the amount of such excess and it shall be deemed a debt due by the Contractor to the Employer and shall be recoverable accordingly. Unless prohibited by law, the Contractor shall, if so instructed by the Engineer within 14 days of such entry and termination referred to in Sub-Clause 63. 1, assign to the Employer the benefit of any agreement for the supply of any goods or materials or services and/or for the execution of any work for the purposes of the Contract, which the Contractor may have entered into. If, by reason of any accident, or failure, or other event occurring to, in, or in connection with the Works, or any part thereof, either during the execution of the Works, or during the Defects Liability Period, any remedial or other work is, in the opinion of the Engineer, urgently necessary for the safety of the Works and the Contractor is unable or unwilling at once to do such work, the Employer shall be entitled to employ and pay other persons to carry out such work as the Engineer may consider necessary. If the work or repair so done by the Employer is work which, in the opinion of the Engineer, the Contractor was liable to do at his own cost under the Contract, then all costs consequent thereon or incidental thereto shall, after due consultation with the Employer and the Contractor, be determined by the Engineer and shall be recoverable from the Contractor by the Employer, and may be deducted by the Employer from any monies due or to become due to the Contractor and the Engineer shall notify the Contractor accordingly, with a copy to the Employer. Provided that the Engineer shall, as soon after the occurrence of any such emergency as may be reasonably practicable, notify the Contractor thereof.  FIDIC 1987 32 Special Risks No Liability for 65.1 Special Risks Special Risks 65.2 Damage to Works 65.3 by Special Risks Projectile, Missile 65.4 Increased Costs 65.5 arising from Special Risks Outbreak of War 65.6 The Contractor shall be under no liability whatsoever in consequence of any of the special risks referred to in Sub-Clause 65.2, whether by way of indemnity or otherwise, for or in respect of: (a) destruction of or damage to the Works, save to work condemned under the provisions of Clause 39 prior to the occurrence of any of the said special risks, (b) destruction of or damage to property, whether of the Employer or third parties, or (c) injury or loss of life. The special risks are: (a) the risks defined under paragraphs (a), (c), (d) and (e) of Sub-Clause 20.4, and (b) the risks defined under paragraph (b) of Sub-Clause 20.4 insofar as these relate to the country in which the Works are to be executed. If the Works or any materials or Plant on or near or in transit to the Site, or any of the Contractor's Equipment, sustain destruction or damage by reason of any of the said special risks, the Contractor shall be entitled to payment in accordance with the Contract for any Permanent Works duly executed and for any materials or Plant so destroyed or damaged and, so far as may be required by the Engineer or as may be necessary for the completion of the Works, to payment for: (a) rectifying any such destruction or damage to the Works, and (b) replacing or rectifying such materials or Contractor’s Equipment, and the Engineer shall determine an addition to the Contract Price in accordance with Clause 52 (which shall in the case of the cost of replacement of Contractor's Equipment include the fair market value thereof as determined by the Engineer) and shall notify the Contractor accordingly, with a copy to the Employer. Destruction, damage, injury or loss of life caused by the explosion or impact, whenever and wherever occurring, of any mine, bomb, shell, grenade, or other projectile, missile, munition, or explosive of war, shall be deemed to be a consequence of the said special risks. Save to the extent that the Contractor is entitled to payment under any other provision of the Contract, the Employer shall repay to the Contractor any costs of the execution of the Works (other than such as may be attributable to the cost of reconstructing work condemned under the provisions of Clause 39 prior to the occurrence of any special risk) which are howsoever attributable to or consequent on or the result of or in any way whatsoever connected with the said special risks, subject however to the provisions in this Clause hereinafter contained in regard to outbreak of war, but the Contractor shall, as soon as any such cost comes to his knowledge, forthwith notify the Engineer thereof. The Engineer shall, after due consultation with the Employer and the Contractor, determine the amount of the Contractor’s costs in respect thereof which shall be added to the Contract Price and shall notify the Contractor accordingly, with a copy to the Employer. If, during the currency of the Contract, there is an outbreak of war, whether war is declared or not, in any part of the world which, whether financially or otherwise, materially affects the execution of the Works, the Contractor shall, unless and until the Contract is terminated under the provisions of this Clause, continue to use his best endeavours to complete the execution of the Works. Provided that the Employer shall be entitled, at any time after such outbreak of war, to terminate the Contract by giving notice to the Contractor and, upon such notice being given, the Contract shall, except as to the rights of the parties under this Clause and Clause 67, terminate, but without prejudice to the rights of either party in respect of any antecedent breach thereof.  FIDIC 1987 33 Removal of 65.7 Contractor's Equipment on Termination Payment if 65.8 Contract Terminated If the Contract is terminated under the provisions of Sub-Clause 65.6, the Contractor shall, with all reasonable dispatch, remove from the Site all Contractor’s Equipment and shall give similar facilities to his Subcontractors to do so. If the Contract is terminated as aforesaid, the Contractor shall be paid by the Employer, insofar as such amounts or items have not already been covered by payments on account made to the Contractor, for all work executed prior to the date of termination at the rates and prices provided in the Contract and in addition: (a) the amounts payable in respect of any preliminary items referred to in the Bill of Quantities, so far as the work or service comprised therein has been carried out or performed, and a proper proportion of any such items which have been partially carried out or performed; (b) the cost of materials, Plant or goods reasonably ordered for the Works which have been delivered to the Contractor or of which the Contractor is legally liable to accept delivery, such materials, Plant or goods becoming the property of the Employer upon such payments being made by him; (c) a sum being the amount of any expenditure reasonably incurred by the Contractor in the expectation of completing the whole of the Works insofar as such expenditure has not been covered by any other payments referred to in this Sub-Clause; (d) any additional sum payable under the provisions of Sub-Clauses 65.3 and 65.5; (e) such proportion of the cost as may be reasonable, taking into account payments made or to be made for work executed, of removal of Contractor’s Equipment under Sub-Clause 65.7 and, if required by the Contractor, return thereof to the Contractor’s main plant yard in his country of registration or to other destination, at no greater cost; and (f) the reasonable cost of repatriation of all the Contractor’s staff and workmen employed on or in connection with the Works at the time of such termination. Provided that against any payment due from the Employer under this Sub-Clause, the Employer shall be entitled to be credited with any outstanding balances due from the Contractor for advances in respect of Contractor's Equipment, materials and Plant and any other sums which, at the date of termination, were recoverable by the Employer from the Contractor under the terms of the Contract. Any sums payable under this Sub-Clause shall, after due consultation with the Employer and the Contractor, be determined by the Engineer who shall notify the Contractor accordingly, with a copy to the Employer. Release from Performance Payment in Event 66.1 of Release from Performance If any circumstance outside the control of both parties arises after the issue of the Letter of Acceptance which renders it impossible or unlawful for either or both parties to fulfil his or their contractual obligations, or under the law governing the Contract the parties are released from further performance, then the parties shall be discharged from the Contract, except as to their rights under this Clause and Clause 67 and without prejudice to the rights of either party in respect of any antecedent breach of the Contract, and the sum payable by the Employer to the Contractor in respect of the work executed shall be the same as that which would have been payable under Clause 65 if the Contract had been terminated under the provisions of Clause 65.  FIDIC 1987 34 Settlement of Disputes Engineer’s 67.1 Decision Amicable 67.2 Settlement Arbitration 67.3 If a dispute of any kind whatsoever arises between the Employer and the Contractor in connection with, or arising out of, the Contract or the execution of the Works, whether during the execution of the Works or after their completion and whether before or after repudiation or other termination of the Contract, including any dispute as to any opinion, instruction, determination, certificate or valuation of the Engineer, the matter in dispute shall, in the first place, be referred in writing to the Engineer, with a copy to the other party. Such reference shall state that it is made pursuant to this Clause. No later than the eighty-fourth day after the day on which he received such reference the Engineer shall give notice of his decision to the Employer and the Contractor. Such decision shall state that it is made pursuant to this Clause. Unless the Contract has already been repudiated or terminated, the Contractor shall, in every case, continue to proceed with the Works with all due diligence and the Contractor and the Employer shall give effect forthwith to every such decision of the Engineer unless and until the same shall be revised, as hereinafter provided, in an amicable settlement or an arbitral award. If either the Employer or the Contractor be dissatisfied with any decision of the Engineer, or if the Engineer fails to give notice of his decision on or before the Eighty-fourth day after the day on which he received the reference, then either the Employer or the Contractor may, on or before the seventieth day after the day on which he received notice of such decision, or on or before the seventieth day after the day on which the said period of 84 days expired, as the case may be, give notice to the other party, with a copy for information to the Engineer, of his intention to commence arbitration, as hereinafter provided, as to the matter in dispute. Such notice shall establish the entitlement of the party giving the same to commence arbitration, as hereinafter provided, as to such dispute and, subject to Sub-Clause 67.4, no arbitration in respect thereof may be commenced unless such notice is given. If the Engineer has given notice of his decision as to a matter in dispute to the Employer and the Contractor and no notice of intention to commence arbitration as to such dispute has been given by either the Employer or the Contractor on or before the seventieth day after the day on which the parties received notice as to such decision from the Engineer, the said decision shall become final and binding upon the Employer and the Contractor. Where notice of intention to commence arbitration as to a dispute has been given in accordance with Sub-Clause 67.1, the parties shall attempt to settle such dispute amicably before the commencement of arbitration. Provided that, unless the parties otherwise agree, arbitration may be commenced on or after the fifty-sixth day after the day on which notice of intention to commence arbitration of such dispute was given, even if no attempt at amicable settlement thereof has been made. Any dispute in respect of which: (a) the decision, if any, of the Engineer has not become final and binding pursuant to Sub-Clause 67. 1, and (b) amicable settlement has not been reached within the period stated in Sub-Clause 67.2, shall be finally settled, unless otherwise specified in the Contract, under the Rules of Conciliation and Arbitration of the International Chamber of Commerce by one or more arbitrators appointed under such Rules. The said arbitrator/s shall have full power to open up, review and revise any decision, opinion, instruction, determination, certificate or valuation of the Engineer related to the dispute. Neither party shall be limited in the proceedings before such arbitrator/s to the evidence or arguments put before the Engineer for the purpose of obtaining his said decision pursuant to Sub-Clause 67.1. No such decision shall disqualify the Engineer from being called as a witness and giving evidence before the arbitrator/s on any matter whatsoever relevant to the dispute.  FIDIC 1987 35 Failure to Comply 67.4 with Engineer’s Decision Arbitration may be commenced prior to or after completion of the Works, provided that the obligations of the Employer, the Engineer and the Contractor shall not be altered by reason of the arbitration being conducted during the progress of the Works. Where neither the Employer nor the Contractor has given notice of intention to commence arbitration of a dispute within the period stated in Sub-Clause 67.1 and the related decision has become final and binding, either party may, if the other party fails to comply with such decision, and without prejudice to any other rights it may have, refer the failure to arbitration in accordance with Sub-Clause 67.3. The provisions of Sub-Clauses 67.1 and 67.2 shall not apply to any such reference. Notices Notice to 68.1 Contractor Notice to 68.2 Employer and Engineer Change of 68.3 Address All certificates, notices or instructions to be given to the Contractor by the Employer or the Engineer under the terms of the Contract shall be sent by post, cable, telex or facsimile transmission to or left at the Contractor's principal place of business or such other address as the Contractor shall nominate for that purpose. Any notice to be given to the Employer or to the Engineer under the terms of the Contract shall be sent by post, cable, telex or facsimile transmission to or left at the respective addresses nominated for that purpose in Part 11 of these Conditions. Either party may change a nominated address to another address in the country where the Works are being executed by prior notice to the other party, with a copy to the Engineer, and the Engineer may do so by prior notice to both parties. Default of Employer Default of 69.1 In the event of the Employer: Employer (a) failing to pay to the Contractor the amount due under any certificate of the Engineer within 28 days after the expiry of the time stated in Sub-Clause 60.10, within which payment is to be made, subject to any deduction that the Employer is entitled to make under the Contract, (b) interfering with or obstructing or refusing any required approval to the issue of any such certificate, (c) becoming bankrupt or, being a company, going into liquidation, other than for the purpose of a scheme of reconstruction or amalgamation, or (d) giving notice to the Contractor that for unforeseen economic reasons it is impossible for him to continue to meet his contractual obligations, the Contractor shall be entitled to terminate his employment under the Contract by giving notice to the Employer, with a copy to the Engineer. Such termination shall take effect 14 days after the giving of the notice. Upon the expiry of the 14 days' notice referred to in Sub-Clause 69.1, the Contractor shall, notwithstanding the provisions of Sub-Clause 54.1, with all reasonable despatch, remove from the Site all Contractor’s Equipment brought by him thereon. In the event of such termination the Employer shall be under the same obligations to the Contractor in regard to payment as if the Contract had been terminated under the provisions of Clause 65, but, in addition to the payments specified in Sub-Clause 65.8, the Employer shall pay to the Contractor the amount of any loss or damage to the Contractor arising out of or in connection with or by consequence of such termination. Removal of 69.2 Contractor’s Equipment Payment on 69.3 Termination  FIDIC 1987 36 Contractor’s 69.4 Entitlement to Suspend Work Resumption 69.5 of Work Without prejudice to the Contractor’s entitlement to interest under Sub-Clause 60.10 and to terminate under Sub-Clause 69.1, the Contractor may, if the Employer fails to pay the Contractor the amount due under any certificate of the Engineer within 28 days after the expiry of the time stated in Sub-Clause 60.10 within which payment is to be made, subject to any deduction that the Employer is entitled to make under the Contract, after giving 28 days’ prior notice to the Employer, with a copy to the Engineer, suspend work or reduce the rate of work. If the Contractor suspends work or reduces the rate of work in accordance with the provisions of this Sub-Clause and thereby suffers delay or incurs costs the Engineer shall, after due consultation with the Employer and the Contractor, determine: (a) any extension of time to which the Contractor is entitled under Clause 44, and (b) the amount of such costs, which shall be added to the Contract Price, and shall notify the Contractor accordingly, with a copy to the Employer. Where the Contractor suspends work or reduces the rate of work. having given notice in accordance with Sub-Clause 69.4, and the Employer subsequently pays the amount due, including interest pursuant to Sub-Clause 60.10, the Contractor's entitlement under Sub-Clause 69.1 shall, if notice of termination has not been given, lapse and the Contractor shall resume normal working as soon as is reasonably possible. Changes in Cost and Legislation Increase or 70.1 Decrease of Cost Subsequent 70.2 Legislation There shall be added to or deducted from the Contract Price such sums in respect of rise or fall in the cost of labour and/or materials or any other matters affecting the cost of the execution of the Works as may be determined in accordance with Part II of these Conditions. If, after the date 28 days prior to the latest date for submission of tenders for the Contract there occur in the country in which the Works are being or are to be executed changes to any National or State Statute, Ordinance, Decree or other Law or any regulation or bye-law of any local or other duly constituted authority, or the introduction of any such State Statute, Ordinance, Decree, Law, regulation or bye-law which causes additional or reduced cost to the Contractor, other than under Sub-Clause 70.1, in the execution of the Contract, such additional or reduced cost shall, after due consultation with the Employer and the Contractor, be determined by the Engineer and shall be added to or deducted from the Contract Price-and the Engineer shall notify the Contractor accordingly, with a copy to the Employer. Currency and Rates of Exchange Currency 71.1 Restrictions Rates of 72.1 Exchange If, after the date 28 days prior to the latest date for submission of tenders for the Contract, the Government or authorised agency of the Government of the country in which the Works are being or are to be executed imposes currency restrictions and/or transfer of currency restrictions in relation to the currency or currencies in which the Contract Price is to be paid, the Employer shall reimburse any loss or damage to the Contractor arising therefrom, without prejudice to the right of the Contractor to exercise any other rights or remedies to which he is entitled in such event. Where the Contract provides for payment in whole or in part to be made to the Contractor in foreign currency or currencies, such payment shall not be subject to variations in the rate or rates of exchange between such specified foreign currency or currencies and the currency of the country in which the Works are to be executed.  FIDIC 1987 37 Currency 72.2 Proportions Currencies of 72.3 Payment for Provisional Sums Where the Employer has required the Tender to be expressed in a single currency but with payment to be made in more than one currency and the Contractor has stated the proportions or amounts of other currency or currencies in which he requires payment to be made, the rate or rates of exchange applicable for calculating the payment of such proportions or amounts shall, unless otherwise stated in Part II of these Conditions, be those prevailing, as determined by the Central Bank of the country in which the Works are to be executed, on the date 28 days prior to the latest date for the submission of tenders for the Contract, as has been notified to the Contractor by the Employer prior to the submission of tenders or as provided for in the Tender. Where the Contract provides for payment in more than one currency, the proportions or amounts to be paid in foreign currencies in respect of Provisional Sums shall be determined in accordance with the principles set forth in Sub-Clauses 72.1 and 72.2 as and when these sums are utilised in whole or in part in accordance with the provisions of Clauses 58 and 59. REFERENCE TO PART II As stated in the Foreword at the beginning of this document, the FIDIC Conditions comprise both Part I and Part II. Certain Clauses, namely Sub-Clauses 1.1 paragraph (a) (i) and (v), 5.1 (part), 14.1, 14.3, 68.2 and 70.1 must include additional wording in Part II for the Conditions to be complete. Other Clauses may require additional wording to supplement Part I or to cover particular circumstances or the type of work (dredging is an example). Part II Conditions of Particular Application with guidelines for the preparation of Part II are printed in a separately bound document.  FIDIC 1987 38 PART 1 - GENERAL CONDITIONS Index Access to Site Access to Works, Engineer Access, Contractor to Satisfy Himself Accident or Injury to Workmen - Insurance Against Accident or Injury to Workmen - Liability for Address, Change of Adequacy of Insurance Adjustment of Contract Price if Variations Exceed 15 per cent of Tender Sum Agreement Alterations, Additions and Omissions Ambiguities in Contract Documents Amicable Settlement of Disputes Appointment of Assistants to Engineer Approval by the Engineer Approval of Materials not Implied Approval Only by Defects Liability Certificate Arbitration Assignment of Contract Avoidance of Damage to Roads Clause 42.1 37.1 11.1 24.2 24.1 68.3 25.2 52.3 9.1 51. & 52. 5.2 67.2 2.4 7.3 54.8 61.1 67.3 3.1 30.1 Bills of Quantities -Estimated Only Boreholes and Exploratory Excavation Breakdown of Lump Sum Items 55.1 18.1 52.7 Care of Works Cash Flow Estimate to be Submitted Certificate, Final Payment Certificates and Payment, Monthly Statements Certificates, Correction of Certificate, Taking-Over Certification of Completion of Works Certification of Completion of Sections or Parts Cessation of Employer's Liability Change of Address, Notice of Claims, Contemporary Records Claims, Notice of Claims, Payment of Claims, Substantiation of Claims Under Performance Security Clearance of Site on Completion Commencement of Works Completion of Works, Time for Completion of Works, Time for, Extension of Completion, Statement at Compliance with Insurance Policy Conditions Compliance with Statutes and Regulations Contemporary Records for Claims Contract Agreement Contractor Not Relieved of Duties or Responsibilities Contractor’s Employees Contractor’s Employees, Engineer at Liberty to Object Contractor’s Entitlement to Suspend Work for Employer's Default Contractor’s Equipment, Conditions of Hire Contractor’s Equipment, Employer not Liable for Damage 20.1 14.3 60.8 60.1 60.5 48.1 48.1 48.2 60.9 68.3 53.2 53.1 53.5 53.3 10.3 33.1 41.1 43.1 44.1 60.5 25.4 26.1 53.2 9.1 14.4 16.1 16.2 69.4 54.5 54.2  FIDIC 1987 Index Contractor’s Equipment, Insurance of Contractor’s Equipment, Reference in Subcontracts Contractor’s Equipment, Temporary Works and Materials; Exclusive Use for the Works Contractor’s Equipment, Transport of Contractor’s Failure to Carry Out Instructions Contractor’s Failure to Insure, Remedy Contractor’s General Responsibilities Contractor’s Superintendence Contractor to Keep Site Clear Contractor to Search Correction of Certificates Cost of Remedying Defects Cost of Samples Cost of Tests Cost of Tests not Provided for Covering up Work, Examination Before Cross Liabilities Currencies of Payment for Provisional Sums Currencies, Rates of Exchange Currency Restrictions Custody and Supply of Drawings and Documents Customs Clearance Damage to Persons and Property Damage to Roads, Avoidance of Damage to Works, Special Risks Damages, Liquidated Dates for Inspection and Testing Daywork Decrease or Increase of Costs Default of Contractor in Compliance with Instructions on Improper Work Default of Contractor, Remedies for Default of Employer Defective Materials and Work Defects, Contractor to Search for, if Required Defects, Cost of Remedying Defects Liability Certificate Defects Liability Period Defects, Remedying of Definitions Delay, Liquidated Damages for Delays and Cost of Delay of Drawings Design by Nominated Subcontractors Discharge Discrepancies in Documents Dismissal of Contractor's Employees Disorderly Conduct, etc. Disputes, Engineer's Decision Disruption of Progress Documents Mutually Explanatory Drawings Drawings and Documents-Custody and Supply of Drawings and Instructions-Supplementary Drawings, Copy to be Kept on Site Drawings, Delays and Cost of Delay of Drawings Drawings, Failure by Contractor to Submit Employer not Liable for Damage to Contractor's Equipment etc.  FIDIC 1987 Clause 21.1 54.7 54.1 30.2 49.4 25.3 8.1 15.1 32.1 50.1 60.4 49.3 36.2 36.3 36.4 38.1 23.3 72.3 72.1 71.1 6.1 54.3 22.1 30.1 65.3 47.1 37.3 52.4 70.1 39.2 63.1 69.1 39.1 50.1 49.3 62.1 49.1 49.2 1.1 47.1 6.4 59.3 60.7 5.2 16.2 34.1 67.1 6.3 5.2 6&7 6.1 7.1 6.2 6.4 6.5 54.2 ii Index Clause Employer’s Liability, Cessation of Employer’s Responsibilities Employer’s Risks Engagement of Staff and Labour Engineer’s Authority to Delegate Engineer’s Determination Where Tests not Provided for Engineer’s Duties and Authority Engineer to Act Impartially Environment - Protection of Errors in Setting Out Evidence and Terms of Insurance Examination of Work before Covering Up Exceptions Exchange, Rates of Exclusions Extension of Time, due to Employer's Failure to give Possession of Site Extension of Time for Completion Extension of Time for Completion, Contractor's Claim Extension of Time for Completion, Engineer's Determination Extraordinary Traffic 60.9 34.1 20.4 34.1 2.3 36.5 2.1 2.6 19.1 17.1 25.1 38.1 22.2 72.1 21.4 42.2 44.1 44.2 44.3 30. Facilities for Other Contractors Facilities - Rights of Way and Failure by Contractor to Submit Drawings Failure to Comply with Claims Procedure Failure to Comply with Engineer's Decision Failure to Give Possession of Site Faulty Work, Removal of Fees and Notices Fencing, Watching, Lighting, etc. Final Payment Certificate Final Statement Foreign Currencies, Payment in Fossils Foundations, Examination of 31.2 42.3 6.5 53.4 67.4 42.2 39.1 26.1 19.1 60.8 60.6 72. 27.1 38.1 General Responsibilities of Contractor Giving of Notices - Payment of Fees 8.1 26.1 Headings and Marginal Notes Improper Work and Materials, Removal of Increase or Decrease of Costs Indemnity by Contract Indemnity by Employer Independent Inspection Injury to Persons - Damage to Property Injury to Workmen Inspection and Testing Inspection and Testing, Dates for Inspection of Foundations, etc. Inspection of Operations Inspection of Site by Contractor Instructions for Variations Instructions in Writing Instructions, Supplementary Insurance, Adequacy of  FIDIC 1987 1.2 39.1 70.1 22.1 & 24.1 22.3 37.5 22.1 24.1 37.2 37.3 38.1 37.1 11.1 51.2 2.5 7.1 25.2 iii Index Clause Insurance, Evidence and Terms of Insurance, Minimum Amount of Insurance of Works and Contractor's Equipment Insurance, Remedy on Failure to Insure Insurance, Responsibility for Amounts not Recovered Insurance, Scope of Cover Insurance, Third Party Insurance, Workmen Interference with Traffic and Adjoining Properties Interim Determination of Extension Interpretations 25.1 23.2 21.1 25.3 21.3 21.2 23.1 24.2 29.1 44.3 1.3 Labour, Engagement of Language/s and Law Law to which Contract Subject Legislation, Subsequent Lighting, Fencing, Watching, etc. Liquidated Damages for Delay Liquidated Damages, Reduction of Loss or Damage due to Employer's Risks Loss or Damage - Responsibility to Rectify Lump Sum Items - Breakdown of 34.1 5.1 5.1 70.2 19.1 47.1 47.2 20.3 20.2 57.2 Materials and Plant, Transport of Materials - Approval of, etc, not Implied Materials, Improper - Removal of Materials, Quality of Materials, Supply of Measurement by Engineer Measurement, Method of Measurement, Quantities Estimated Only Methods of Construction Minimum Amount of Insurance Monthly Payments 30.3 54.8 39.1 36.1 8.1 56.1 57.1 55.1 8.2 23.2 60.2 Nominated Subcontractors, Certification of Payments to Nominated Subcontractors, Definition Nominated Subcontractors, Design by Nominated Subcontractors, Objection to Nomination Nominated Subcontractors, Payment to Not Foreseeable Physical Obstructions or Conditions Notice of Claims Notices and Fees, Payment of Notices, Consents and Approvals Notice to Contractor Notice to Employer and Engineer 59.5 59.1 59.3 59.2 59.4 12.2 53.1 26.1 1.5 68.1 68.2 Objections to Contractor's Employees Obstructions or Conditions - Not Foreseeable Physical Omissions, Alterations and Additions Openings, Uncovering and making Operations, Inspection of Order of Work, Contractor to Furnish Programme Other Contractors, Opportunities for 16.2 12.2 59. 38.2 37.1 14.1 31.1 Patent Rights Payment if Contract Terminated for Contractor's Default Payment if Contract Terminated for Employer's Default Payment of Claims 28.1 63.3 69.3 53.5  FIDIC 1987 iv Index Payment, Time for Performance Security Performance Security-Claims Under Performance Security-Period of Validity Period of Defects Liability Permanent Works Designed by Contractor Physical Obstructions or Conditions-Not Foreseeable Physical Obstructions or Conditions-Engineer’s Determination Plant and Materials, Transport of Plant, Conditions of Hire Plant, Customs Clearance Plant, Employer not Liable for damage to Plant, etc.-Exclusive Use for the Works Plant, Quality of Plant, Re-export of Plant, Removal of Policy of Insurance-Compliance with Conditions Possession of Site Possession of Site, Failure to Give Power of Engineer to Fix Rates Priority of Contract Documents Programme to be Submitted Progress-Disruption of Progress-Rate of Protection of Environment Provision to Indemnify Contractor Provision to Indemnify Employer Provisional Sums, Currencies of Payment Provisional Sums, Definition Provisional Sums, Production of Vouchers Provisional Sums, Use of Clause 60.10 10.1 10.3 10.2 49.1 7.2 12.2 12.3 30.3 54.5 54.3 54.2 54.1 36.1 54.4 39.1 25.4 42.1 42.2 52.2 5.2 14.1 6.3 46.1 19.1 22.3 22.2 72.3 58.1 58.3 58.2 Quality of Materials and Workmanship Quantities 36.1 55.1 Rate of Progress Rates of Exchange Rates, Power of Engineer to Fix Rectification of Loss or Damage Reduction of Liquidated Damages Re-export of Plant Regulations, Statutes, etc., Compliance with Rejection Release from Performance Remedies for Default of Contractor Remedying of Defects Remedying of Defects, Cost of Remedy on Contractor's Failure to Insure Removal of Contractor's Employees Removal of Contractor's Equipment Removal of Improper Work, Materials or Plant Removal of Plant, etc. Responsibility to Rectify Loss or Damage Responsibility Unaffected by Approval Restriction on Working Hours Resumption of Work Retention Money, Payment of Returns of Labour and Contractor’s Equipment 46.1 72.1 52.2 20.2 47.2 54.4 26.1 37.4 66.1 63.1 49.2 49.3 25.3 16.2 69.2 39.1 65.7 20.2 7.3 45.1 69.5 60.3 35.1  FIDIC 1987 v Index Clause Revised Programme Rights of Way and Facilities Risks, Employer's Risks, Special Roads, etc., - Damage by Extraordinary Traffic Roads, Interference with Access to Royalties 14.2 42.3 20.4 65. 30.1 29.1 28.2 Safety, Security and Protection of the Environment Samples, Cost of Security, Safety and Protection of the Environment Setting-Out Singular and Plural Site, Clearance on Completion Site, Contractor to Keep Clear Site, Inspection of by Contractor Site Operations and Methods of Construction Site, Possession of Special Risks Staff, Engagement of Statement at Completion Statement, Final Statutes, Regulations, etc. - Compliance with Subcontracting Subcontractors, Nominated Subcontractors, Responsibility of the Contractor for Acts and Default of Subsequent Legislation Substantial Completion of Sections or Parts Sufficiency of Tender Supply of Plant, Materials and Labour Surfaces Requiring Reinstatement Suspension, Engineer's Determination Suspension lasting more than 84 days Suspension of Work 19.1 36.2 19.1 17.1 1.4 33.1 32.1 11.1 8.2 42.1 65 34.1 60.5 60.6 26.1 4.1 59 4.1 70.2 48.3 12.1 8.1 48.4 40.2 40.3 40.1 Taking Over Certificate Taking Over of Sections or Parts Tender Documents Tender, Sufficiency of Termination of Contract by Employer Termination of Contract by Employer, Assignment of Benefit Terms of Insurance Tests, Cost of Tests not Provided for - Cost of Third Party Insurance Time for Completion Time for Completion, Extension of Time for Payment Traffic, Extraordinary Traffic, Interference with Traffic, Waterbome Transport of Contractor’s Equipment and Temporary Works Transport of Materials and Plant Uncovering Work and Making Openings Unfulfilled Obligations Urgent Remedial Work  FIDIC 1987 48.1 48.2 11.1 12.1 63.1 63.4 25.1 36.3 36.4 23.1 43.1 44.1 60.10 30.1 29.1 30.4 30.2 30.3 38.2 62.2 64.1 vi Index Clause Valuation at Date of Termination by the Employer Variations Variations, Daywork Basis Variations, Exceeding 15 per cent Variations, Instructions for Variations, Power of the Engineer to Fix Rates Variations, Valuation of Vouchers, Production of 63.2 51.1 52.4 52.3 51.2 52.2 51.3 58.3 War, Outbreak of Watching and Lighting, etc. Waterbome Traffic Work, Examination of Before Covering Up Work, Improper, Removal of Working Hours, Restriction of Workmanship, Quality of Workmen, Accident or Injury to Works, Care of Works, Completion of (Defects Liability Certificate) Works, Commencement of Works, Insurance of Works, Remedying of Defects Works, Time for Completion of Works to be Measured Work, Suspension of Work to be in Accordance with the Contract 20.4 19.1 30.4 38.1 39.1 45.1 36.1 24.1 20.1 62.1 41.1 21.1 49.2 43.1 56.1 40.1 13.1  FIDIC 1987 vii FEDERATION INTERNATIONALE DES INGENIEURS-CONSEILS CONDITIONS OF CONTRACT FOR WORKS OF CIVIL ENGINEERING CONSTRUCTION FORMS OF TENDER AND AGREEMENT FOURTH EDITION 1987 Reprinted 1988 with editorial amendments Reprinted 1992 with further amendments TENDER NAME OF CONTRACT: _____________________________________________ __________________________________________________________________________ TO _______________________________________________________________ ___________________________________________________________________ Gentlemen, 1. Having examined the Conditions of Contract, Specification, Drawings, and Bill of Quantities and Addenda Nos ______ for the execution of the above-named Works, we, the undersigned, offer to execute and complete such Works and remedy any defects therein in conformity with the Conditions of Contract, Specification, Drawings, Bill of Quantities and Addenda for the sum of ___________________________________________________________________ ___________________________________________________________________ 2. ( ________________________________________________________________ ) or such other sum as may be ascertained in accordance with the said Conditions. We acknowledge that the Appendix forms part of our Tender. 3. We undertake, if our Tender is accepted, to commence the Works as soon as is reasonably possible after the receipt of the Engineer's notice to commence, and to complete the whole of the Works comprised in the Contract within the time stated in the Appendix to Tender. 4. We agree to abide by this Tender for the period of *______days from the date fixed for receiving the same and it shall remain binding upon us and maybe accepted at any time before the expiration of that period. 5. Unless and until a formal Agreement is prepared and executed this Tender, together with your written acceptance thereof, shall constitute a binding contract between us. 6. We understand that you are not bound to accept the lowest or any tender you may receive. Dated this ________________________ day of _______________________ 20 __ Signature ________________________ in the capacity of ____________________ duly authorised to sign tenders for and on behalf of _________________________ ___________________________________________________________________ (IN BLOCK CAPITALS) Address __________________________________________________________________ __________________________________________________________________________ Witness __________________________________________________________________ Address ____________________________________________________________ __________________________________________________________________________ Occupation _________________________________________________________ __(Note: All details marked * shall be inserted before issue of Tender documents.) Appendix Sub – Clause Amount of security (if any) 10.1 ______________ per cent of the Contract Price Minimum amount of third party insurance Time for issue of notice to commence 23.2 _________________ per occurrence, with the number of occurrences unlimited 41.1 ________________ days Time for Completion 43.1 ________________ days Amount of liquidated damages 47.1 ______________ per day Limit of liquidated damage 47.1 ____________________ Defects Liability Period 49.1 ________________ days Percentage for adjustment of Provisional Sums 59.4(c) ____________ per cent Percentage of invoice value of listed materials and Plant 60.1(c) ____________ per cent Percentage of Retention 60.2 ______________ per cent Limit of Retention Money Minimum Amount of Interim Payment Certificates 60.2 ____________________ 60.2 ____________________ Rate of interest upon unpaid sums 60.10 ____ per cent per annum Initials of Signatory of Tender __________________________________________ (Notes: All details in the list above, other than percentage figure against Sub-Clause 59.4, shall be inserted before issue of Tender documents. Where a number of days is to be inserted, it is desirable, for consistency with the Conditions, that the number should be a multiple of seven. Additional entries are necessary where provision is included in the Contract for: (a) completion of Sections (Sub-Clauses 43.1 and 48.2(a)) (b) liquidated damages for Sections (Sub-Clause 47. 1) (c) a bonus (Sub-Clause 47.3 - Part II) (d) payment for materials on Site (Sub-Clause 60. 1 (c)) (e) payment in foreign currencies (Clause 60 - Part II) (f) an advance payment (Clause 60 - Part II) (g) adjustments to the Contract Price on account of Specified Materials (Sub-Clause 70.1 - Part 11) (h) rates of exchange (Sub-Clause 72.2 - Part II)) Agreement This Agreement made the ___________________ day of ________________ 20 Between ___________________________________________________________ of ____________________________________________________________________ _______________________ (hereinafter called “the Employer”) of the one part and _______________________________________of __________________________ (hereinafter called “the Contractor”) of the other part Whereas the Employer is desirous that certain Works should be executed by the Contractor, viz ______________________________________________________ and has accepted a Tender by the Contractor for the execution and completion of such Works and the remedying of any defects therein 1. 2. Now this Agreement witnesseth as follows: In this Agreement words and expressions shall have the same meanings as are respectively assigned to them in the Conditions of Contract hereinafter referred to. The following documents shall be deemed to form and be read and construed as part of this Agreement, viz: (a) The Letter of Acceptance; (b) The said Tender; (c) The Conditions of Contract (Parts I and II); (d) The Specification; (e) The Drawings; and (f) The Bill of Quantities. 3. In consideration of the payments to be made by the Employer to the Contractor as hereinafter mentioned the Contractor hereby covenants with the Employer to execute and complete the Works and remedy any defects therein in conformity in all respects with the provisions of the Contract. 4. The Employer hereby covenants to pay the Contractor in consideration of the execution and completion of the works and the remedying of defects therein the Contract Price or such other sum as may become payable under the provisions of the Contract at the times and in the manner prescribed by the Contract. In Witness whereof the parties hereto have caused this Agreement to be executed the day and year first before written in accordance with their respective laws. The Common Seal of _________________________________________________ __________________________________________________________________________ was hereunto affixed in the presence of: or Signed Sealed and Delivered by the said _______________________________________________________________ in the presence of : FEDERATION INTERNATIONALE DES INGENIEURS-CONSEILS CONDITIONS OF CONTRACT FOR WORKS OF CIVIL ENGINEERING CONSTRUCTION PART II CONDITIONS OF PARTICULAR APPLICATION WITH GUIDELINES FOR PREPARATION OF PART II CLAUSES FOURTH EDITION 1987 Reprinted 1988 with editorial amendments Reprinted 1992 with further amendment CONTENTS PART II: CONDITIONS OF PARTICULAR APPLICATION Introduction (including special reference to Dredging and Reclamation Work) 1 2 5 9 10 11 12 14 15 16 18 19 21 21, 23 & 25 28 31 34 35 40 43 45 47 48 49 50 51 52 54 60 67 68 69 70 72 73 Page 1 Definitions Engineer’s Duties Language/s and Law and Documents Contract Agreement Performance Security Inspection of Site Not Foreseeable Obstructions or Conditions Programme and Cash Flow Estimate Contractor’s Superintendence Contractor’ Boreholes and Exploratory Excavation Safety, Security and Protection of the Environment Insurance of Works and Contractor’s Equipment 3 3 3 4 4 5 5 5 9 9 9 9 10 Insurances Arranged by Employer Royalties Opportunities for other Contractors Labour Records and Reports Suspension Time for Completion Restriction on Working Hours Bonuses Prevention from Testing Defects Liability Contractor to Search Variations Payment in Foreign Currency Vesting of Contractor’s Equipment Certificates and Payments Settlement of Disputes Notices Default of Employer Changes in Cost and Legislation Currency Proportions Additional Clauses INDEX EDITORIAL AMENDMENTS IN 1988 FURTHER AMENDMENTS IN 1992 10 11 12 12 14 14 14 14 15 15 16 16 16 17 17 18 19 20 20 20 24 25 INTRODUCTION The terms of the Fourth Edition of the Conditions of Contract for Works of Civil Engineering Construction have been prepared by the Fédération Internationale des Ingénieurs Conseils (FIDIC) and are recommended for general use for the purpose of construction of such works where tenders are invited on an international basis. The Conditions, subject to minor modifications, are also suitable for use on domestic contracts. The version in English of the Conditions is considered by FIDIC as the official and authentic text for the purpose of translation. The Clauses of general application have been grouped together in a separately bound document and are referred to as Part I-General Conditions. They have been printed in a form which will facilitate their inclusion, as printed, in the contract documents normally prepared. In the preparation of the Conditions it was recognised that while there are numerous Clauses which will be generally applicable there are some Clauses which must necessarily vary to take account of the circumstances and locality of the Works. Part I - General Conditions and Part II - Conditions of Particular Application together comprise the Conditions governing the rights and obligations of the parties. For this reason a Part II standard form has not been produced. It will be necessary to prepare a Part II document for each individual contract and the Guidelines are intended to aid in this task by giving options for various clauses where appropriate. Part II clauses may arise for one or more reasons, of which the following are examples: (i) Where the wording in Part I specifically requires that further information is to be included in Part II and the Conditions would not be complete without that information, namely in Sub-Clauses 1.1 paragraphs (a) (i) and (iv), 5.1 (part), 14.1, 14.3, 68.2 and 70.1 (ii) Where the wording in Part I indicates that supplementary information may be included in Part 11, but the conditions would still be complete without any such information, namely in Sub-Clauses 2.1 paragraph (b), 5.1 (part), 21.1 paragraph (b) and 72.2. (iii) Where the type, circumstances or locality of the Works necessitates additional Clauses or Sub-Clauses. (iv) Where the law of the country or exceptional circumstances necessitate an alteration in Part I. Such alterations should be effected by stating in Part II that a particular Clause, or part of a Clause, in Part I is deleted and giving the substitute Clause, or part, as applicable. As far as possible, in the Clauses that are mentioned hereunder, example wording is provided. In the case of some Clauses, however, only an aide-memoire for the preparation is given. Before incorporating any example wording it must be checked to ensure that it is wholly suitable for the particular circumstances and, if not, it must be varied. Where example wording is varied and in all cases where additional material is included in Part II, care must be taken that no ambiguity is created with Part 1 or between the Clauses in Part II. 1 Dredging and Reclamation Work Special consideration must be given to Part II where dredging and certain types of reclamation work are involved. Dredgers are considerably more expensive than most items of Contractor's Equipment and the capital value of a dredger can often exceed the value of the Contract on which it is used. For this reason, it is in the interests of both the Employer and the Contractor that a dredger is operated intensively in the most economic fashion, subject to the quality of work and any other over-riding factors. With this end in view, it is customary to allow the Contractor to execute dredging work continuously by day and by night seven days a week. Another difference from most civil engineering is that on dredging work the Contractor is not normally held responsible for the remedying of defects after the date of completion as certified under Clause 48. Part II contains explanations and example wording to cover the above points and others relating to dredging. Clauses 11, 12, 18, 19,28,40,45,49,50 and 51 are those which most often require attention in Part II when dredging work is involved and reference is included under each of these Clauses. Other Clauses may also need additions in Part II in certain circumstances. Reclamation work varies greatly in character and each instance must be considered before deciding whether it is appropriate to introduce in Part II changes similar to those adopted for dredging, or to use the standard civil engineering form unaltered. 2 PART II CONDITIONS OF PARTICULAR APPLICATION Clause 1 Sub-Clause 1.1 – Definitions Definitions (a) (i) The Employer is (insert name) (a) (iv) The Engineer is (insert name) If further definitions are essential, additions should be made to the list. Clause 2 Sub-Clause 2.1 - Engineer’s Duties Engineer’s Duties EXAMPLE The Engineer shall obtain the specific approval of the Employer before carrying out his duties in accordance with the following Clauses of Part 1: (a) Clause (insert applicable number) (b) Clause (insert applicable number) (c) Clause (insert applicable number) This list should be extended or reduced as necessary. In some cases the obligation to obtain the approval of the Employer may apply to only one Sub-Clause out of several in a Clause or approval may only be necessary beyond certain limits, monetary or otherwise. Where this is so, the example wording must be varied. If the obligation to obtain the approval of the Employer could lead to the Engineer being unable to take action in an emergency, where matters of safety are involved, an additional paragraph may be necessary. EXAMPLE Notwithstanding the obligation, as set out above, to obtain approval, if, in the opinion of the Engineer, an emergency occurs affecting the safety of life or of the Works or of adjoining property, he may, without relieving the Contractor of any of his duties and responsibilities under the Contract, instruct the Contractor to execute all such work or to do all such things as may, in the opinion of the Engineer, be necessary to abate or reduce the risk. The Contractor shall forthwith comply, despite the absence of approval of the Employer, with any such instruction of the Engineer. The Engineer shall determine an addition to the Contract Price, in respect of such instruction, in accordance with Clause 52 and shall notify the Contractor accordingly, with a copy to the Employer. Clause 5 Sub-Clause 5.1 - Language/s and Law Language/s and Law and Documents (a) The language is (insert as applicable) (b) The law is that in force in (insert name of country) If necessary (a) above should be varied to read: The languages are (insert as applicable) and there should be added The Ruling Language is (insert as applicable) 3 Sub-Clause 5.2 - Priority of Contract Documents tract Agreement Where it is decided that an order of precedence of all documents should be included, this Sub-Clause may be varied as follows: EXAMPLE Delete the documents listed 1 - 6 and substitute: (1) the Contract Agreement (if completed); (2) the Letter of Acceptance; (3) the Tender; (4) the Conditions of Contract Part II; (5) the Conditions of Contract Part I; (6) the Specification; (7) the Drawings; and (8) the priced Bill of Quantities or Where it is decided that no order of precedence of documents should be included, this Sub-Clause may be varied as follows: EXAMPLE Delete the text of the Sub-Clause and substitute: The several documents forming the Contract are to be taken as mutually explanatory of one another, but in the case of ambiguities or discrepancies the priority shall be that accorded by law. If, in the opinion of the Engineer, such ambiguities or discrepancies make it necessary to issue any instruction to the Contractor in explanation or adjustment, the Engineer shall have authority to issue such instruction. Contract Agreement Clause 9 Where it is decided that a Contract Agreement should be entered into and executed the form must be annexed to these Conditions as stated in Sub-Clause 9.1 of Part I of these Conditions. A suitable form is annexed to Part I - General Conditions. Clause 10 Performance Security Sub-Clause 10.1 - Performance Security Where it is decided that a performance security should be obtained by the Contractor, the form must be annexed to these Conditions as stated in Sub-Clause 10.1 of Part I of these Conditions. Two example forms of performance security are given on pages 7, 8 and 9. The Clause and wording of the example forms may have to be varied to comply with the law of the Contract which may require the forms to be executed under seal. Where there is provision in the Contract for payments to the Contractor to be made in foreign currency, Sub-Clause 10. 1 of Part I of these Conditions may be varied. EXAMPLE After the first sentence, insert the following sentence: The security shall be denominated in the types and proportions of currencies stated in the Appendix to Tender. Where the source of the performance security is to be restricted, an additional Sub-Clause may be added. 4 Source of 10.4 Performance Security EXAMPLE SUB-CLAUSES The performance security, submitted by the Contractor in accordance with Sub-Clause 10.1, shall be furnished by an institution registered in (insert the country where the Works are to be executed) or licensed to do business in such country. or Source of 10.4 Performance Security Where the performance security is in the form of a bank guarantee, it shall be issued by: (a) a bank located in the country of the Employer, or (b) a foreign bank through a correspondent bank located in the country of the Employer. Clause 11 Where the bulk or complexity of the data, or reasons of security enforced by the country where the Works are to be executed, makes it impracticable for the Employer to make all data available with the Tender Documents and inspection of some data by the Contractor at an office is therefore expected, it would be advisable to make the circumstances clear. Inspection of Site Access 11.2 to Data EXAMPLE SUB-CLAUSE Data made available by the Employer in accordance with Sub-Clause 11.1 shall be deemed to include data listed elsewhere in the Contract as open for inspection at (insert particulars of the office or offices where such data is stored) Sub-Clause 11.1 - Inspection of Site For a Contract comprising dredging and reclamation work the Clause may be varied as follows: EXAMPLE In the first paragraph, delete the words “hydrological and sub-surface” and substitute “hydrographic and sub-seabed”. In the second paragraph, under (a) delete the word "sub-surface” and substitute 11 "sub-seabed” and under (b) delete the word "hydrological” and substitute "hydrographic”. Clause 12 Sub-Clause 12.2 - Not Foreseeable Obstructions or Condition For a Contract comprising dredging and some types of reclamation work the Sub-Clause may require to be varied. Not Foreseeable Obstructions or Conditions EXAMPLE Delete the words ", other than climatic conditions on the Site,”. Clause 14 Sub-Clause 14.1 - Programme to be Submitted The time within which the programme shall be submitted shall be (insert number) days. Programme and Cash Flow Estimate Sub-Clause 14.3 - Cash Flow Estimate to be Submitted The time within which the detailed cash flow estimate shall be submitted shall be (insert number) days. In both examples given above it is desirable for consistency with the rest of the Conditions that the number of days inserted should be a multiple of seven. 5 EXAMPLE PERFORMANCE GUARANTEE Contractor’s Superintendence By this guarantee We ________________________________________________ whose registered office is at ___________________________________________ (hereinafter called "the Contractor”) and ________________________________ whose registered vice is at ____________________________________________ (hereinafter called "the Guarantor”) are held and firmly bound unto _____________________________________ (hereinafter called "the Employer”) in the sum of ______________________________ for the payment of which sum the Contractor and the Guarantor bind themselves, their successors and assigns jointly and severally by these presents. Whereas the Contractor by an Agreement made between the Employer of the one part and the Contractor of the other part has entered into a Contract (hereinafter called "the said Contract ”) to execute and complete certain Works and remedy any defects therein as therein mentioned in conformity with the provisions of the said Contract. Now the Condition of the above-written Guarantee is such that if the Contractor shall duly perform and observe all the terms provisions conditions and stipulations of the said Contract on the Contractor’s part to be performed and observed according to the true purport intent and meaning thereof or if on default by the Contractor the Guarantor shall satisfy and discharge the damages sustained by the Employer thereby up to the amount of the above-written Guarantee then this obligation shall be null and void but otherwise shall be and remain in full force and effect but no alteration in terms of the said Contract or in the extent or nature of the Works to be executed, completed and defects therein remedied thereunder and no allowance of time by the Employer or the Engineer under the said Contract nor any forbearance or forgiveness in or in respect of any matter or thing concerning the said Contract on the part of the Employer or the said Engineer shall in any way release the Guarantor from any liability under the above-written Guarantee. Provided always that the above obligation of Guarantor to satisfy and discharge the damages sustained by the Employer shall arise only (a) on written notice from both the Employer and the Contractor that the Employer and the Contractor have mutually agreed that the amount of damages concerned is payable to the Employer or (b) on receipt by the Guarantor of a legally certified copy of an award issued in arbitration proceeding carried out in conformity with the terms of the said Contract that the amount of the damages is payable to the Employer. Signed on ________________________Signed on _________________________ on behalf of ______________________on behalf of _______________________ by ______________________________by _______________________________ in the capacity of __________________in the capacity of ___________________ in the presence of __________________in the presence of __________________ 6 EXAMPLE SURETY BOND FOR PERFORMANCE Know all Men by these Presents that (name and address of Contractor) __________________________________________________________________ __________________________________________________________________ as Principal (hereinafter called "the Contractor”) and (name, legal title and address of Surety ___________________________________________________ __________________________________________________________________ as Surety (hereinafter called "the Surety”), are held and firmly bound unto (name and address of Employer ________________________________________ __________________________________________________________________ __________________________________________as Obligee (hereinafter called "the Employer") in the amount of __________ for the payment of which sum, well and truly to be made, the Contractor and the Surety bind themselves, their successors and assigns, jointly and severally, firmly by these presents. Whereas the Contractor has entered into a written contract agreement with the Employer dated the___________________ day of ____________________ 20 __ for (name of Works __________________________________________________ in accordance with the plans and specifications and amendments thereto, to the extent herein provided for, are by reference made part hereof and are hereinafter referred to as the Contract. Now, therefore, the Condition of this Obligation is such that, if the Contractor shall promptly and faithfully perform the said Contract (including any amendments thereto) then this obligation shall be null and void; otherwise it shall remain in full force and effect. Whenever Contractor shall be, and declared by Employer to be, in default under the Contract, the Employer having performed the Employer's obligations thereunder, the Surety may promptly remedy the default, or shall promptly: (1) Complete the Contract in accordance with its terms and conditions; or (2) Obtain a bid or bids for submission to the Employer for completing the Contract in accordance with its terms and conditions, and upon determination by Employer and Surety of the lowest responsible bidder, arrange for a contract between such bidder and Employer and make available as work progresses (even though there should be a default or a succession of defaults under the contract or contracts of completion arranged under this paragraph) sufficient funds to pay the cost of completion less the balance of the Contract Value; but not exceeding, including other costs and damages for which the Surety may be liable hereunder, the amount set forth in the first paragraph hereof. The term "balance of the Contract Value", as used in this paragraph, shall mean the total amount payable by Employer to Contractor under the Contract, less the amount properly paid by Employer to Contractor; or (3) Pay the Employer the amount required by Employer to complete the Contract in accordance with its terms and conditions any amount up to a total not exceeding the amount of this Bond. 7 The Surety shall not be liable for a greater sum than the specified penalty of this Bond. Any suit under this Bond must be instituted before the issue of the Defects Liability Certificate. No right of action shall accrue on this Bond to or for the use of any person or corporation other than the Employer named herein or the heirs, executors, administrators or successors of the Employer. Signed on__________________________ Signed on _______________________ on behalf of ________________________ on behalf of _____________________ by ________________________________ by ____________________________ in the capacity ______________________ in the capacity __________________ in the presence of ____________________ in the presence of ________________ 8 Clause 15 Where the language in which the Contract documents have been drawn up is not the language of the country in which the Works are to be executed, or where for any other reason it is necessary to stipulate that the Contractor's authorised representative shall be fluent in a particular language, an additional Sub-Clause may be added. Language Ability 15.2 of Contractor’s Representative or Interpreter to be 15.2 Made Available EXAMPLE SUB-CLAUSES The Contractor’s authorised representative shall be fluent in (insert name of language). If the Contractor’s authorised representative is not, in the opinion of the Engineer, fluent in (insert name of language), the Contractor shall have available on Site at all times a competent interpreter to ensure the proper transmission of instructions and information. Clause 16 Where the language in which the Contract documents have been drawn up is not the language of the country in which the Works are to be executed, or where for any other reason it is necessary to stipulate that members of the Contractor’s superintending staff shall be fluent in a particular language, an additional Sub-Clause may be added. Language Ability 16.3 of Superintending Staff EXAMPLE SUB-CLAUSE A reasonable proportion of the Contractor’s superintending staff shall have a working knowledge of (insert name of language) or the Contractor shall have available on Site at all times a sufficient number of competent interpreters to ensure the proper transmission of instructions and information. Where there is a desire, but not a legal requirement, that the Contractor makes reasonable use of materials from or persons resident in the country in which the Works are to be executed, an additional Sub-Clause may be added. EXAMPLE SUB-CLAUSE Employment of 16.4 The Contractor is encouraged, to the extent practicable and reasonable, to Local Personnel employ staff and labour from sources within (insert name of country). holes and Exploratory Excavation Clause 18 Sub-Clause 18.1 - Boreholes and Exploratory Excavation For a Contract comprising dredging and reclamation work the Sub-Clause may require to be varied. EXAMPLE Add second sentence as follows: Such exploratory excavation shall be deemed to include dredging. Safety, Security and Protection of the Environment Clause 19 Sub-Clause 19.1 - Safety, Security and Protection of the Environment Where a Contract includes dredging the possibility of pollution should be given particular attention and additional wording may be required. For example, where fishing and recreation areas might be influenced, the Contractor should be required to plan and execute the dredging so that the effect is kept to a minimum. Where there is a risk of chemical pollution from soluble sediments in the dredging area, for instance in a harbour, it is important that sufficient information is provided with the Tender documents. Responsibilities should be clearly defined. 9 Clause 21 Sub-Clause 21.1 - Insurance of Works and Contractor’s Equipment Where there is provision in the Contract for payments to the Contractor to be made in foreign currency, this Sub-Clause may be varied. EXAMPLE Add final sentence as follows: The insurance in paragraphs (a) and (b) shall provide for compensation to be payable in the types and proportions of currencies required to rectify the loss or damage incurred. Where it is decided to state the deductible limits for the Employer’s Risks, this Sub-Clause may be varied. EXAMPLE Add to paragraph (a) as follows: and with deductible limits for the Employer's Risks not exceeding (insert amounts) s Arranged by Employer Clauses 21, 23 and 25. Insurances Arranged by Employer In certain circumstances, such as where a number of separate contractors are employed on a single project, or phased take-over is involved, it may be preferable for the Employer to arrange insurance of the Works, and Third Party insurance. In such case, it must be clear in the Contract that the Contractor is not precluded from taking out any additional insurance, should he desire to do so, over and above that to be arranged by the Employer. Tenderers must be provided at the Tender stage with details of the insurance to be arranged by the Employer, in order to assess what provision to make in their rates and prices for any additional insurance, and for the amount of policy deductibles which they will be required to bear. Such details shall form part of the Contract between the Employer and the Contractor. Example wording to allow for the arrangement of insurance by the Employer is as follows: EXAMPLE Clause 21 Delete the text of the Clause and substitute the following re-numbered Sub-Clauses: Insurance 21.1 of Works Without limiting his or the Contractor's obligations and responsibilities under Clause 20, the Employer will insure: (a) the Works, together with materials and Plant for incorporation therein, to the full replacement cost (the term "cost” in this context shall include profit), and (b) an additional sum to cover any additional costs of and incidental to the rectification of loss or damage including professional fees and the cost of demolishing and removing any part of the Works and of removing debris of whatsoever nature. Insurance of 21.2 Contractor's Equipment The Contractor shall, without limiting his obligations and responsibilities under Clause 20, insure the Contractor’s Equipment and other things brought onto the site by the Contractor, for a sum sufficient to provide for their replacement at the Site. Scope of Cover 21.3 The insurance in Sub-Clause 21.1 shall be in the joint names of the Contractor and the Employer and shall cover: 10 (a) the Employer and the Contractor against loss or damage as provided in the details of insurance annexed to these Conditions, from the start of work at the Site until the date of issue of the relevant Taking-Over Certificate in respect of the Works or any Section or part thereof as the case may be, and (b) the Contractor for his liability: (i) during the Defects Liability Period for loss or damage arising from a cause occurring prior to the commencement of the Defects Liability Period, or (ii) occasioned by the Contractor in the course of any operations carried out by him for the purpose of complying with his obligations under Clauses 49 and 50. Responsibility for 21.4 Amounts not Recovered Any amounts not insured or not recovered from the insurers shall be borne by the Employer or the Contractor in accordance with their responsibilities under Clause 20. Clause 23 Delete the text of the Clause and substitute: Third Party 23.1 Insurance (including Employer’s Property) Without limiting his or the Contractor's obligations and responsibilities under Clause 22, the Employer will insure in the joint names of the Contractor and the Employer, against liabilities for death of or injury to any person (other than as provided in Clause 24) or loss of or damage to any property other than the Works) arising out of the performance of the Contract, as provided in the details of insurance referred to in Sub-Clause 21.3. Clause 25 Delete the text of the Clause and substitute: Evidence 25.1 and Terms of Insurances The insurance policies to be arranged by the Employer pursuant to Clauses 21 and 23 shall be consistent with the general terms described in the Tender and copies of such policies shall when required be supplied by the Employer to the Contractor. Adequacy of 25.2 Insurances The Employer shall notify the insurers of changes in the nature, extent or programme for execution of the Works and ensure the adequacy of the insurances at all times in accordance with the terms of the Contract and shall, when required, produce to the Contractor the insurance policies in force and the receipts for payment of the premiums. No variations shall be made to the insurances by the Employer without the prior approval of the Contractor. If and so far as the Employer fails to effect and keep in force any of the insurances referred to in Sub-Clause 25.1, then the Contractor may effect and keep in force any such insurance and pay any premium as may be necessary for that purpose and add the amount so paid to any monies due or to become due to the Contractor, or recover the same as a debt due from the Employer. In the event that the Contractor or the Employer fails to comply with conditions imposed by the insurance policies effected pursuant to the Contract, each shall indemnify the other against all losses and claims arising from such failure. Remedy on 25.3 Employer's Failure to Insure Compliance with 25.4 Policy Conditions Clause 28 Sub-Clause 28.2 – Royalties Royalties For a Contract comprising dredging and reclamation work and for any other Contract involving the dumping of materials the Sub-Clause may require to be varied. EXAMPLE Add second sentence as follows: The Contractor shall also be liable for all payments or compensation, if any, levied in relation to the dumping of part or all of any such materials. 11 It is sometimes the case on dredging contracts for the Employer to bear the costs of tonnage and other royalties, rent and other payments or compensation. If such conditions are to apply, Sub-Clause 28.2 should be varied either by adding wording or by deleting the existing wording and substituting new wording. Opportunities for other Contractors Clause 31 Where the particular requirements of other contractors are known within reasonable limits at the time of preparation of the Contract documents, details must be stated. The Specification is usually the appropriate place to do so but, exceptionally, some reference may be desirable in the Conditions. In that case, an additional Sub-Clause or Sub-Clauses could be added to this Clause. Labour Clause 34 It will generally be necessary to add a number of Sub-Clauses, to take account of the circumstances and locality of the Works, covering such matters as: permits and registration of expatriate employees; repatriation to place of recruitment; provision of temporary housing for employees; requirements in respect of accommodation for staff of Employer and Engineer; standards of accommodation to be provided; provision of access roads, hospital, school, power, water, drainage, fire services, refuse collection, communal buildings, shops, telephones; hours and conditions of working; rates of pay; compliance with labour legislation; maintenance of records of safety and health. EXAMPLE SUB-CLAUSES (to be numbered, as appropriate) Rates of Wages 34. The Contractor shall pay rates of wages and observe conditions of labour not less and Conditions favourable than those established for the trade or industry where the work is of Labour carried out. In the absence of any rates of wages or conditions of labour so established, the Contractor shall pay rates of wages and observe conditions of labour which are not less favourable than the general level of wages and conditions observed by other employers whose general circumstances in the trade or industry in which the Contractor is engaged are similar. Employment of 34. The Contractor shall not recruit or attempt to recruit his staff and labour from Persons in the amongst persons in the service of the Employer or the Engineer. Service of Others Repatriation of 34. The Contractor shall be responsible for the return to the place where they were Labour recruited or to their domicile of all such persons as he recruited and employed for the purposes of or in connection with the Contract and shall maintain such persons as are to be so returned in a suitable manner until they shall have left the Site or, in the case of persons who are not nationals of and have been recruited outside (insert name of country), shall have left (insert name of country). Housing for Labour 34. Save insofar as the Contract otherwise provides, the Contractor shall provide and maintain such accommodation and amenities as he may consider necessary for all his staff and labour, employed for the purposes of or in connection with the Contract, including all fencing, water supply (both for drinking and other purposes), electricity supply, sanitation, cookhouses, fire prevention and fire-fighting equipment, air conditioning, cookers, refrigerators, furniture, and other requirements in connection with such accommodation or amenities. On completion of the Contract, unless otherwise agreed with the Employer, the temporary camps/housing provided by the Contractor shall be removed and the site reinstated to its original condition, all to the approval of the Engineer. Accident Prevention Officer, Accidents 34. The Contractor shall have on his staff at the Site an officer dealing only with questions regarding the safety and protection against accidents of all staff and labour. This officer shall be qualified for this work and shall have the authority to issue instructions and shall take protective measures to prevent accidents. 12 Health and Safety 34. Due precautions shall be taken by the Contractor, and at his own cost, to ensure the safety of his staff and labour and, in collaboration with and to the requirements of the local health authorities, to ensure that medical staff first aid equipment and stores, sick bay and suitable ambulance service are available at the camps, housing and on the Site at all times throughout the period of the Contract and that suitable arrangements are made for the prevention of epidemics and for all necessary welfare and hygiene requirements. Measures against Insect and Pest Nuisance 34. The Contractor shall at all times take the necessary precautions to protect all staff and labour employed on the site from insect nuisance, rats and other pests and reduce the dangers to health and the general nuisance occasioned by the same. The Contractor shall provide his staff and labour with suitable prophylactics for the prevention of malaria and take steps to prevent the formation of stagnant pools of water. He shall comply with all the regulations of the local health authorities in these respects and shall in particular arrange to spray thoroughly with approved insecticide all buildings erected on the Site. Such treatment shall be carried out at least once a year or as instructed by the Engineer. The Contractor shall warn his staff and labour of the dangers of bilharzia and wild animals. Epidemics 34. In the event of any outbreak of illness of an epidemic nature, the Contractor shall comply with and carry out such regulations, orders and requirements as may be made by the Government, or the local medical or sanitary authorities, for the purpose of dealing with and overcoming the same. Burial of the Dead 34. The Contractor shall make all necessary arrangements for the transport, to any place as required for burial, of any of his expatriate employees or members of their families who may die in (insert name of country). The Contractor shall also be responsible, to the extent required by the local regulations, for making any arrangements with regard to burial of any of his local employees who may die while engaged upon the Works. Supply of Foodstuffs 34. The Contractor shall arrange for the provision of a sufficient supply of suitable food at reasonable prices for all his staff, labour and Subcontractors, for the purposes of or in connection with the Contract. Supply of Water 34. The Contractor shall, so far as is reasonably practicable, having regard to local conditions, provide on the Site an adequate supply of drinking and other water for the use of his staff and labour. Alcoholic Liquor or Drugs 34. The Contractor shall not, otherwise than in accordance with the Statutes, Ordinances and Government Regulations or Orders for the time being in force, import, sell, give, barter or otherwise dispose of any alcoholic liquor or drugs, or permit or suffer any such importation, sale, gift, barter or disposal by his Subcontractors, agents, staff or labour. Arms and Ammunition 34. The Contractor shall not give, barter or otherwise dispose of to any person or persons, any arms or ammunition of any kind or permit or suffer the same as aforesaid. Festivals and Religious Customs Disorderly Conduct 34. The Contractor shall in all dealings with his staff and labour have due regard to all recognised festivals, days of rest and religious or other customs. The Contractor shall at all times take all reasonable precautions to prevent any unlawful, riotous or disorderly conduct by or amongst his staff and labour and for the preservation of peace and protection of persons and property in the neighbourhood of the Works against the same. 34. 13 Clause 35ports ports Additional Sub-Clauses may be desirable to cover circumstances which require the maintenance of particular records or the provision of certain specific reports. Records of Safety and Health 35. Reporting of Accidents 35. EXAMPLE SUB-CLAUSES (to be numbered, as appropriate) The Contractor shall maintain such records and make such reports concerning safely, health and welfare of persons and damage to property as the Engineer may from time to time prescribe. The Contractor shall report to the Engineer details of any accident as soon as possible after its occurrence. In the case of any fatality or serious accident, the Contractor shall, in addition, notify the Engineer immediately by the quickest available means. Suspension Clause 40 For a Contract comprising dredging and some types of reclamation work the Clause may be varied. Sub-Clause 40.1 - Suspension of Work EXAMPLE Delete paragraph (c) and renumber paragraph (d) as (c). Sub-Clause 40.3 - Suspension Lasting more than 84 Days EXAMPLE In the first sentence delete the words ", (c) or (d) ” and substitute "or (c) ”. Time for Completion Clause 43 Sub-Clause 43.1 - Time for Completion Where completion is stated to be by a date and not within a period of time, the Sub-Clause will require to be varied. EXAMPLE Delete the words, "within the time... such extended time” and substitute "by the date or dates stated in the Appendix to Tender for the whole of the Works or the Section (as the case may be) or such later date or dates”. Restriction on Working Hours Clause 45 For a Contract located in an isolated area, where environmental restrictions do not apply, or where a Contract comprises work, such as dredging and reclamation, that may require continuous working, the Clause may be varied. Working Hours 45.1 EXAMPLE Delete Sub-Clause 45.1 and substitute: Subject to any provision to the contrary contained in the Contract, the Contractor shall have the option to work continuously by day and by night and on locally recognised days of rest. The Contractor’s option may be further extended by substituting, in place of the last three words: holidays or days of rest. 14 Clause 47 Where it is desired to make provision for the payment of a bonus or bonuses for early completion, an additional Sub-Clause may be added. In the case where a bonus is provided for early completion of the whole of the Works: EXAMPLE SUB-CLAUSE Bonus for 47.3 If the Contractor achieves completion of the Works prior to the time prescribed Completion by Clause 43, the Employer shall pay to the Contractor a sum of (insert figure) for every day which shall elapse between the date stated in the Taking-Over Certificate in respect of the Works issued in accordance with Clause 48 and the time prescribed in Clause 43. Bonuses or In the case where bonuses are provided for early completion of Sections of the Works and details, other than the dates, are given in the Specification: Bonus for 47.3 Completion EXAMPLE SUB-CLAUSE Sections are required to be completed by the dates given in the Appendix to Tender in order that such Sections may be occupied and used by the Employer in advance of the completion of the whole of the Works. Details of the work required to be executed to entitle the Contractor to bonus payments and the amount of the bonuses are stated in the Specification. For the purposes of calculating bonus payments, the dates given in the Appendix to Tender for completion of Sections are fixed and, unless otherwise agreed, no adjustments of the dates by reason of granting an extension of time pursuant to Clause 44 or any other Clause of these Conditions will be allowed. Issue of certificates by the Engineer that the Sections were satisfactory and complete by the dates given on the certificates shall, subject to Clause 60, entitle the Contractor to the bonus payments calculated in accordance with the Specification. Clause 48 Where it can be foreseen that, when the whole of the Works have been substantially completed, the Contractor may be prevented by reasons beyond his control from carrying out the Tests on Completion, an additional Sub-Clause may be added. Prevention from Testing EXAMPLE SUB-CLAUSE Prevention 48.5 If the Contractor is prevented from carrying out the Tests on Completion by a from Testing cause for which the Employer or the Engineer or other contractors employed by the Employer are responsible, the Employer shall be deemed to have taken over the Works on the date when the Tests on Completion would have been completed but for such prevention. The Engineer shall issue a Taking-Over Certificate accordingly. Provided always that the Works shall not be deemed to have been taken over if they are not substantially in accordance with the Contract. If the Works are taken over under this Sub-Clause the Contractor shall nevertheless carry out the Tests on Completion during the Defects Liability notice. Any additional costs to which the Contractor may be put, in making the Tests on Completion during the Defects Liability Period, shall be added to the Contract Price. 15 Clause 49 For a Contract which includes a high proportion of Plant, an additional Sub-Clause may be necessary. EXAMPLE SUB-CLAUSE Extension of 49.5 The provisions of this Clause shall apply to all replacements or renewals of Plant Defects Liability carried out by the Contractor to remedy defects and damage as if the replacements and renewals had been taken over on the date they were completed. The Defects Liability Period for the Works shall be extended by a period equal to the period during which the Works cannot be used by reason of a defect or damage. If only part of the Works is affected the Defects Liability Period shall be extended only for that part. In neither case shall the Defects Liability Period extend beyond 2 years from the date of taking over. Defects Liability When progress in respect of Plant has been suspended under Clause 40, the Contractor's obligations under this Clause shall not apply to any defects occurring more than 3 years after the Time for Completion established on the date of the Letter of Acceptance. For a Contract comprising dredging work an additional Sub-Clause may be added. EXAMPLE SUB-CLAUSE No Remedying 49.5 Notwithstanding Sub-Clause 49.2, the Contractor shall have no responsibility for of Defects in the remedying of defects, shrinkages or other faults in respect of dredging work Dredging Work after the date stated in the Taking-Over Certificate. after Completion Contractor to Search Clause 50 For a Contract comprising dredging work and where the second Example Sub-Clause 49.5 has been adopted, an additional Sub-Clause should be added. EXAMPLE SUB-CLAUSE No Responsibility 50.2 Notwithstanding Sub-Clause 50.1, the Contractor shall have no responsibility to for Cost of bear the cost of searching for any defect, shrinkage or other fault in respect of Searching of dredging work after the date stated in the Taking-Over Certificate. Dredging Work Variations Clause 51 Sub-Clause 51.1 - Variations For a Contract comprising dredging and some types of reclamation work the Sub-Clause may require to be varied. EXAMPLE Add final sentence as follows: Provided also that the Contractor shall be under no obligation to execute any variation which cannot be executed by the Contractor’s Equipment being used or to be used on the Works. 16 Clause 52 Where provision is made in the Contract for payment in foreign currency, this Clause may be varied. Sub-Clause 52.1 - Valuation of Variations EXAMPLE Add final sentence as follows: Payment in Foreign Currency The agreement, fixing or determination of any rates or prices as aforesaid shall include any foreign currency and the proportion thereof. Sub-Clause 52.2 -Power of Engineer to Fix Rates Add to first paragraph final sentence as follows: The agreement or fixing of any rates or prices as aforesaid shall include any foreign currency and the proportion thereof. Sub-Clause 52.3 - Variations Exceeding 15 per cent Add final sentence as follows: The adjustment or fixing of any sum as aforesaid shall have due regard to any foreign currency included in the Effective Contract Price and the proportion thereof. Where it is required to place some limitation on the range of items for which the rates and prices may be subject to review, the Clause may be varied. Sub-Clause 52.2 - Power of Engineer to Fix Rates EXAMPLE At the end of the first paragraph add: Provided further that no change in the rate or price for any item contained. in the Contract shall be considered unless such item accounts for an amount more than 2 per cent of the Contract Price, and the actual quantity of work executed under the item exceeds or falls short of the quantity set out in the Bill of Quantities by more than 25 per cent. Vesting of Contractor’s Equipment Clause 54 Where vesting of Contractor’s Equipment, Temporary Works and materials in the Employer is required, additional Sub-Clauses may be added. EXAMPLE WORDING AND SUB-CLAUSES Sub-Clauses 54.2 and 54.3 shall be renumbered as 54.3 and 54.4 and Sub-Clauses 54.4 to 54.8 shall be renumbered as 54.6 to 54.10. Add additional Sub-Clauses as follows: Vesting 54.2 All Contractor’s Equipment, Temporary Works and materials owned by the Contractor, or by any company in which the Contractor has a controlling interest, shall, when on the Site, be deemed to be the properly of the Employer. Provided always that the vesting of such property in the Employer shall not prejudice the right of the Contractor to the sole use of the said Contractor’s Equipment, Temporary Works and materials for the purpose of the Works nor shall it affect the Contractor’s responsibility to operate and maintain the same under the provisions of the Contract. Revesting and 54.5 Removal Upon the removal, with the consent of the Engineer under Sub-Clauses 54.1, of any such Contractor's Equipment, Temporary Works or materials as have been deemed to have become the property of the Employer under Sub-Clause 54.2, the property therein shall be deemed to revest in the Contractor and, upon completion of the Works, the property in the remainder of such Contractor’s Equipment, Temporary Works and materials shall, subject to Clause 63, be deemed to revest in the Contractor. 17 Clause 60 Additional Sub-Clauses may be necessary to cover certain other matters relating to payments. Certificates and Payments Where payments are to be made in various currencies in predetermined proportions and calculated at fixed rates of exchange the following 3 Sub-Clauses, which should be taken together, may be added: EXAMPLE SUB-CLAUSES (to be numbered, as appropriate) Currency 60. The currency of account shall be the (insert name of currency) and for the Of Account purposes of the Contract conversion between (insert name of currency) and other and Rates currencies stated in the Appendix to Tender shall be made in accordance with the of Exchange Table of Exchange Rates in the Appendix to Tender. Conversion between the currencies stated in such Table other than the (insert name of currency) shall be made at rates of exchange determined by use of the relative rates of exchange between such currencies and the (insert name of currency) set out therein. Payments to Contractor 60. All payments to the Contractor by the Employer shall be made: (a) in the case of payment(s) under Sub-Clause(s) 70.2 and (insert number of any other applicable Clause), in (insert name of currency/ies); (b) in the case of payments for certain provisional sum items excluded from the Appendix to Tender, in the currencies and proportions applicable to these items at the time when the Engineer gives instructions for the work covered by these items to be carried out; and (c) in any other case, including Increase or Decrease of Costs under Sub-Clause 70.1, in the currencies and proportions stated in the Appendix to Tender as applicable to such payment provided that the proportions of currencies stated in the Appendix to Tender may from time to time upon the application of either party be varied as may be agreed. Payments to Employer 60. All payments to the Employer by the Contractor including payments made by way of deduction or set-off shall be made: (a) in the case of credit(s) under Sub-Clause(s) 70.2 and (insert number of any other applicable Clause) in (insert name of currency/ies); (b) in the case of liquidated damages under Clause 47, in (insert name of currency/ies); (c) in the case of reimbursement of any sum previously expended by the Employer, in the currency in which the sum was expended by the Employer; and (d) in any other case, in such currency as may be agreed. If the part payable in a particular currency of any sum payable to the Contractor is wholly or partly insufficient to satisfy by way of deduction or set-off a payment due to the Employer in that currency, in accordance with the provisions of this Sub-Clause, then the Employer may if he so desires make such deduction or set-off wholly or partly as the case may be from the balance of such sum payable in other currencies. Where all payments are to be made in one currency the following Sub-Clause may be added: EXAMPLE SUB-CLAUSE (to be numbered, as appropriate) Currency of 60. The currency of account shall be the (insert name of currency) and all payments Account made in accordance with the Contract shall be in (insert name of currency). Such and Payments (insert name of currency), other than for local costs, shall be fully convertible. The percentage of such payments attributed to local costs shall be as stated in the Appendix to Tender. 18 Where place of payment is to be defined the following Sub-Clause may be added: EXAMPLE SUB-CLAUSE (to be numbered, as appropriate) Place of Payment 60. Payments to the Contractor by the Employer shall be made into a bank account nominated by the Contractor in the country of the currency of payment. Where payment is to be made in more than one currency separate bank accounts shall be nominated by the Contractor in the country of each currency and payments shall be made by the Employer accordingly. Where provision is to be included for an advance payment the following Sub-Clause may be added: EXAMPLE SUB-CLAUSE (to be numbered, as appropriate) Advance Payment 60. An advance payment of the amount stated in the Appendix to Tender shall, following the presentation by the Contractor to the Employer of an approved performance security in accordance with Sub-Clause 10.1 and a Guarantee in terms approved by the Employer for the full value of the advance payment, be certified by the Engineer for payment to the Contractor. Such Guarantee shall be progressively reduced by the amount repaid by the Contractor as indicated in Interim Payment Certificates of the Engineer issued in accordance with this Clause. The advance payment shall not be subject to retention. The advance payment shall be repaid by way of reduction in Interim Payment Certificates commencing with the next certificate issued after the total certified value of the Permanent Works and any other items in the Bill of Quantities (excluding the deduction of retention) exceeds (insert figure) per cent of the sum stated in the Letter of Acceptance. The amount of the reduction in each Interim Payment Certificate shall be one (insert fraction) of the difference between the total value of the Permanent Works and any other items in the Bill of Quantities (excluding the deduction of retention) due for certification in such Interim Payment Certificate and the said value in the last preceding Interim Payment Certificate until the advance payment has been repaid in full. Provided upon the issue of a Taking-Over Certificate for the whole of the Works or upon the happening of any of the events specified in Sub-Clause 63.1 or termination under Clauses 65, 66 or 69, the whole of the balance then outstanding shall immediately become due and payable by the Contractor to the Employer. Settlement of Disputes Clause 67 Where it is considered desirable to add to Sub-Clauses 67.3 provisions with respect to the number of arbitrators, the place of arbitration and the language of arbitration, the following paragraphs may be added to Sub-Clause 67.3: EXAMPLE The arbitral tribunal shall consist of ……(a sole or three) arbitrator(s). The place of arbitration shall be ……(city and country). The language of the arbitration shall be ....... It is desirable that the place of arbitration be situated in a state, other than that of the Employer or the Contractor, which has a modem and liberal arbitration law and which has ratified a bilateral or multilateral convention (such as the 1958 New York Convention on the Recognition and Enforcement of Foreign Arbitral Awards), or both, that would facilitate the enforcement of an arbitral award in the states of the parties to the Contract. In the absence of stipulations as to the three above mentioned matters, (number of arbitrators, place of arbitration and language of arbitration), the ICC will decide on the number of arbitrators (typically three in any substantial construction dispute) and on the place of arbitration. The arbitral tribunal will decide on the language of the arbitration if the parties cannot agree. It may also be considered desirable in some cases for other parties to be joined into any arbitration between the Employer and the Contractor, thereby creating a multi-party arbitration. While this may be feasible, multi-party arbitration clauses require skillful draftmanship on a case-by-case basis. No satisfactory standard form of multi-party arbitration clause for international use has yet been developed. 19 Where it is decided that a settlement of dispute procedure, other than that of the International Chamber of Commerce (ICC), should be used the Clause may be varied. Sub-Clause 67.3 - Arbitration EXAMPLE Following paragraph (b), delete the words "shall be finally settled... International Chamber of Commerce” and substitute "shall be finally settled under the UNCITRAL Arbitration Rules as administered by (insert name of administering authority)”. Where alternatives to the ICC are considered care should be taken to establish that the favoured alternative is appropriate for the circumstances of the Contract and that the wording of Clause 67 is checked and amended as may be necessary to avoid any ambiguity with the alternative. Care should be taken to define exactly how the arbitral tribunal is to be appointed and, where appropriate, an appointing authority should be designated. Notices Clause 68 Sub-Clause 68.2 - Notice to Employer and Engineer For the purposes of this Sub-Clause the respective addresses are: (a) The Employer (insert address) (b) The Engineer (insert address) The addresses should be inserted when the documents are being prepared prior to inviting tenders. Default of Employer Clause 69 Sub-Clause 69.1 - Default of Employer Where the Employer is a government it may be considered appropriate to vary the Sub-Clause. EXAMPLE Delete paragraph (c) and renumber paragraph (d) as (c). Where the terms of the Sub-Clause, when read in conjunction with Sub-Clause 69.3, are in conflict with the law of the country the Sub-Clause may require to be varied. EXAMPLE Delete "or” at the end of paragraph (c) and delete paragraph (d). Changes in Cost and Legislation Clause 70 Three alternative methods of dealing with price adjustment are given below. The first alternative is suitable where a contract is of short duration and no price adjustment is to be made: Sub-Clause 70.1-Increase or Decrease in Cost EXAMPLE Delete the text of the Sub-Clause and substitute Subject to Sub-Clause 70.21 the Contract Price shall not be subject to any adjustment in respect of rise or fall in the cost of labour, materials or any other matters affecting the cost of execution of the Contract. Sub-Clause 70.2-Subsequent Legislation EXAMPLE Delete the words ", other than under Sub-Clause 70.1, ” The second alternative is suitable where price adjustment is to be made by establishing the difference in cost between the basic price and the current price of local labour and specified materials: 20 Sub-Clause 70.1 - Increase or Decrease in Cost EXAMPLE Delete the text of the Sub-Clause and substitute Adjustments to the Contract Price shall be made in respect of rise or fall in the cost of local labour and specified materials as set out in this Sub-Clause. (a) Local Workmen (i) For the purpose of this Sub-Clause: "Local Workmen" means skilled, semi-skilled and unskilled workmen of all trades engaged by the Contractor on the Site for the purpose of or in connection with the Contract or engaged full time by the Contractor off the Site for the purpose of or in connection with the Contract (by way of illustration but not limitation: workmen engaged full time in any office, store, (workshop or quarry); “Basic Rate” means the applicable basic minimum wage rate prevailing on the date 28 days prior to the latest date for submission of tenders by reason of any National or State Statute, Ordinance, Decree or other Law or any regulations or bye-law of any local or other duly constituted authority, or in order to conform with practice amongst good employers generally in the area where the Works are to be carried out; and "Current Rate" means the applicable basic minimum wage rate for Local Workmen prevailing on any date subsequent to the date 28 days prior to the latest date set for submission of tenders by reason of any National or State Statute, Ordinance, Decree or other Law or any regulation or bye-law of any local or other duly constituted authority, or in order to conform with practice amongst good employers generally in the area where the works are to be carried out. (ii) The adjustment to the Contract Price under the terms of this Sub-Clause Rates for Local workmen by: (a) the number of all hours actually worked, and (b) in respect of those hours worked at overtime rates, by the product of the number of said hours and the percentage addition required by the law to be paid by the Contractor for overtime. Such adjustment may be either an addition to or a deduction from the Contract Price. (iii) No other adjustment of the Contract Price on account of fluctuation in the remuneration of Local Workmen shall be made. (b) Specified Materials (i) For the purpose of this Sub-Clause: "Specified Materials" means the materials stated in Appendix (insert reference) to Tender required on the Site for the execution and completion of the Works; "Basic Prices” means the current prices for the specified materials prevailing on the date 28 days prior to the latest date for submission of tenders; and "Current Prices" means the current prices for the specified materials prevailing at any date subsequent to the date 28 days prior to the latest date for submission of tenders. (ii) The adjustment to the Contract Price under the terms of this Sub-Clause shall be calculated by applying the difference between the Basic and Current Prices to the quantity of the appropriate Specified Material which is delivered to the Site during the period for which the particular Current Price is effective. Such adjustment may be either an addition to or a deduction from the Contract Price. 21 (iii) The Contractor shall use due diligence to ensure that excessive wastage of the Specified Materials shall not occur. Any Specified Materials removed from the Site shall be clearly identified in the records required under paragraph (d) of this Sub-Clause. (iv) The provisions of this Sub-Clause shall apply to fuels used in Contractor’s Equipment engaged on the Site for the purposes of executing the Works, including vehicles owned by the Contractor (or hired by him under long term arrangements under which the Contractor is obligated to supply fuel) engaged in transporting any staff, labour, Contractor's Equipment, Temporary Works, Plant or materials to and from the Site. Such fuels shall be clearly identified in the records required under paragraph (d) of this Sub-Clause. The provisions of this Sub-Clause shall not apply to any fuels sold or supplied to any employee of the Contractor or to any person for use in any motor vehicle not being used for the purposes of the Contract. (v) The Contractor shall at all times have regard to suitable markets and shall, whenever buying materials a variation in the cost of which would give rise to an adjustment of the Contract Price under this Sub-Clause, be diligent to buy or procure the same at the most economical prices as are consistent with the due performance by the Contractor of his obligations under the Contract. If at any time there shall have been any lack of diligence, default or negligence on the part of the Contractor, whether in observing the above requirements or otherwise, then, for the purposes of adjusting the Contract Price pursuant hereto, no account shall be taken of any increase in cost which may be attributable to such lack of diligence, default or negligence and the amount by which any cost would have been decreased but for such lack of diligence, default or negligence shall be deducted from the Contract Price. (vi) No other adjustment to the Contract Price on account off fluctuation in the cost of materials shall be made. (c) Overheads and Profits Excluded In determining the amount of any adjustment to the Contract Price pursuant to this Sub-Clause no account shall be taken of any overheads or profits. (d) Notices and Records The Contractor shall forthwith, upon the happening of any event which may or may be likely to give rise to adjustment of the Contract Price pursuant to this Sub-Clause, give notice thereof to the Engineer and the Contractor shall keep such books, accounts and other documents and records as are necessary to enable adjustment under this Sub-Clause to be made and shall, at the request of the Engineer, furnish any invoices, accounts, documents or records so kept and such other information as the Engineer may require. (e) Adjustment after Date of Completion Adjustment to the Contract Price, after the due date for completion of the whole of the Works pursuant to Clause 43, or after the date of completion of the whole of the Works certified pursuant to Clause 48, shall be made in accordance with Current Rates or Current Prices, as applicable, ruling at the due date for completion or the date stated in the Taking-Over Certificate, whichever is the earlier. (f) Determination of Adjustment to Contract Price The amount of any adjustment to the Contract Price pursuant to this Sub-Clause shall be determined by the Engineer in accordance with the foregoing rules. 22 EXAMPLE APPENDIX TO TENDER for use in conjunction with the second alternative. SPECIFIED MATERIALS MATERIAL UNIT PRICE AND TRANSPORT LOCATION TO SITE PRICE DELIVERED TO SITE REMARKS Bitumen Diesel Petrol Lubricants Cement Reinforcing Steel Explosives NOTES: 1.The Contractor shall provide copies of quotations to substantiate all prices included in the above table. 2. All subsequent price substantiation shall be from the same source as original unless otherwise agreed by the Engineer. 3. The Contractor shall submit full explanation and provide substantiating documentation for the mode of transport to Site he proposes. Only the proposed documented mode of transport shall qualify or price adjustment. (Note: Materials stated in the Appendix to Tender should be those of which substantial quantities are involved.) The third alternative is suitable where price adjustment is to be made through the application of indices in a formula: Sub-Clause 70.1 - Increase or Decrease in Cost EXAMPLE Delete the text of the Sub-Clause and substitute (a) Adjustments to the Contract Price in respect of rise and fall in the cost of labour and materials and other matters affecting the cost of execution of the Works shall be calculated for each monthly statement pursuant to Sub-Clause 60.1, the Statement at Completion pursuant to Sub-Clause 60.5 and the Final Statement pursuant to Sub-Clause 60.6 in accordance with the provisions of this Sub-Clause if there shall be any changes in the following Index figures compiled by (insert details of source of indices) and published by (insert details of publication): (i) the Index of the cost of Labour in (insert name of country), (ii) the Index of the cost of (insert other factor, as relevant), or (iii) the Index of the cost of (insert other factor, as relevant). (b) For the purpose of this Sub-Clause: (i) "Base Index Figure" shall mean the index figure applicable on the date 28 days prior to the latest date for submission of tenders, and (ii) "Current Index Figure” shall mean the index figure applicable on the last day of the period to which the particular statement relates. Provided that in respect of any work the value of which is included in any such monthly statement (or Statement at Completion or Final Statement) and which was executed after the due date (or extended date) for completion of the whole of the Works, pursuant to Clause 43, the Current Index Figure shall be the index figure applicable on the aforesaid due date (or extended date) for completion of the whole of the Works. 23 (iii) "Effective Value” shall be the difference between: (a) The amount which is due to the Contractor under the provisions of Sub-Clauses 60.2, 60.5 or 60.8 (before deducting retention and excluding repayment of the advance payment) less any amounts for: work executed under nominated Subcontracts materials and Plant on the Site, as referred to in Sub-Clause 60.1 (c) dayworks, variations or any other items based on actual cost or current prices, and bonuses (if any) adjustments under Clause 70, and (b) The amount calculated in accordance with (b) (iii) (a) of this Sub-Clause and included in the last preceding statement. (c) The adjustment to the Contract Price shall be calculated by multiplying the Effective Value by a Price Fluctuation Factor which shall be the net sum of the products obtained by multiplying each of the proportions given in paragraph (d) of this Sub-Clause by the following fraction: Current Index Figure - Base Index Figure Base Index Figure calculated using the relevant index figures. (d) For the purpose of calculating the Price Fluctuation Factor, the proportions referred to in paragraph (c) of this Sub-Clause shall (irrespective of the actual constituents of the work) be as follows: 0. in respect of labour (and supervision) costs subject to adjustment by reference to the Index referred to in (a) (i) of this Sub-Clause; 0. in respect of by reference to the Index referred to in (a) (ii) of this Sub-Clause; 0. in respect of by reference to the Index referred to in (a) (iii) of this Sub-Clause; 0. in respect of all other costs which shall not be subject to any adjustment; 1.00 Total (e) Where the value of an Index is not known at the time of calculation, the latest available value shall be used and any adjustment necessary shall be made in subsequent monthly statements. (Note: The number of indices included under (a) of this Sub-Clause may be varied, if it is determined that a different number of factors should be separately identified, and in such case (d) of this Sub-Clause must be altered to be consistent.) Currency Proportions Clause 72 Sub-Clause 72.2 - Currency Proportions Where it is decided that the rate or rates of exchange shall be established from a source other than the Central Bank of the country, the Sub-Clause may be varied. EXAMPLE Delete the words from "prevailing... ” to the end of the sentence and substitute “stated in the Appendix to Tender”. 24 Clause 73 onwards Where circumstances require, additional Clauses may be added. EXAMPLE CLAUSES (to be numbered, starting with Clause 73, as appropriate). Additional Clauses Where the law applicable to the Contract does not cover bribery, the following example Clause may be added. Bribes .1 If the Contractor or any of his Subcontractors, agents or servants offers to give or agrees to offer or give to any person, any bribe, gift, gratuity or commission as an inducement or reward for doing or forbearing to do any action in relation to the Contract or any other contract with the Employer or for showing or forbearing to show favour or disfavour to any person in relation to the Contract or any other contract with the Employer, then the Employer may enter upon the Site and the Works and terminate the employment of the Contractor and the provisions of Clause 63 hereof shall apply as if such entry and termination had been made pursuant to that Clause. Where circumstances require that particular confidentiality is observed, the following example Clause may be added. Details to be Confidential .1 The Contractor shall treat the details of the Contract as private and confidential, save in so far as may be necessary for the purposes thereof, and shall not publish or disclose the same or any particulars thereof in any trade or technical paper or elsewhere without the previous consent in writing of the Employer or the Engineer. If any dispute arises as to the necessity of any publication or disclosure for the purpose of the Contract the same shall be referred to the Employer whose determination shall be final. Where the Contract is being financed wholly or in part by an international financial institution whose rules or policies require a restriction on the use of the funds provided, the following example Clause may be added. Expenditure Restricted .1 The Contractor shall not make any expenditures for the purpose of the Contract in the territories of any country which is not a member of (insert name of international financial institution) nor shall he make any expenditure for goods produced in or services supplied from such territories. Where the Contractor may be a joint venture, the following example Clause may be added. Joint and Several Liability .1 If the Contractor is a joint venture of two or more persons, all such persons shall be jointly and severally bound to the Employer for the fulfilment of the terms of the Contract and shall designate one of such persons to act as leader with authority to bind the joint venture. The composition or the constitution of the joint venture shall not be altered without the prior consent of the Employer. 25 PART II CONDITIONS OF PARTICULAR APPLICATION Index Clause Access to Data Accident Prevention Officer Accidents, Reporting of Additional Clauses Alcoholic Liquor Arbitration Arms and Ammunition 11.2 34. 35. 73. 34. 67. 34. Bonus for Completion 47.3 Boreholes and Exploratory Excavation Burial of the Dead 18.1 34. Cash Flow Estimate to be Submitted 14.3 Changes in Cost and Legislation Conditions of Labour and Rates of Wages Contract Agreement Contractor's Equipment, Insurance of Contractor's Representative, Language Ability of Currency of Account and Rates of Exchange Currency Proportions 70. 34. 9.1 21.1 15.2 60. 72.2 Data, Access to 11.2 Default of Employer Disorderly Conduct Documents, Order of Precedence Drugs 69.1 34. 5.2 34. Employer, Name and Address Employment of Local Personnel Employment of Persons in Service of Others Engineer, Name and Address Engineer's Duties Environment, Protection of Epidemics Exploratory Excavation and Boreholes Extension of Defects Liability 1.1 16.4 34. 1.1 2.1 19.1 34. 18.1 49.5 Facilities for Other Contractors 31.2 Festivals and Religious Customs Foodstuffs, Supply of 34. 34. Health and Safety of Staff and Labour 34. Housing for Labour 34. Inspection of Site 11.1 Insurance of the Works and Contractor's Equipment Insurances Arranged by the Employer Interpreter to be made Available 21.1 21. 23 & 25 15.2 Labour, Conditions of and Rates of Wages Labour, Health and Safety Labour, Housing for Labour, Rates of Wages and Conditions Labour, Repatriation of Labour, Special Provision for Language, Ability of Contractor's Representative 34. 34. 34. 34. 34. 34. 15.2 26 Index Clause Language, Ability of Superintending Staff Language, Ruling Languages Law Applicable Local Personnel, Employment of 16.3 5.1 5.1 5.1 16.4 Measures Against Insect and Pest Nuisance 34. No Remedying of Defects in Dredging Work after Completion No Responsibility for Cost of Searching of Dredging Work Not Foreseeable Physical Obstructions or Conditions Notice to Employer and Engineer 49.5 50.2 12.2 68.2 Other Contractors, Facilities for Other Contractors, Opportunities for 31.2 31.1 60. 60. 10.1 10.1 10.1 10.4 12.2 60. 52.2 48.5 14.1 19.1 Payments to Employer Performance, Example of Security Bond for Performance Guarantee, Example Performance Security Performance Security, Source of Physical Conditions or Obstructions, Not Foreseeable Place of Payment Power of Engineer to Fix Rates Prevention from Testing Programme to be Submitted Protection of the Environment Rates of Exchange Rates of Wages and Conditions of Labour Records of Safety and Health Religious Customs and Festivals Repatriation of Labour Reporting of Accidents Revesting and Removal of Contractor's Equipment, Temporary Works and Materials Royalties 60. 34. 35. 34. 34. 35. Safety, Security and Protection of the Environment Security, Safety and Protection of the Environment Site, Inspection of Source of Performance Security Staff, Health and Safety of Submission of Cash Flow Estimate Submission of Programme Superintending Staff, Language Ability of Supply of Foodstuffs Supply of Water Surety Bond for Performance, Example of Suspension of Work 19.1 19.1 11.1 10.4 34. 14.3 14.1 16.3 34. 34. 10.1 40.1 Testing, Prevention from Time for Completion 48.5 43.1 Valuation of Variations Variations Variations Exceeding 15 per cent Vesting of Contractor's Equipment, Temporary Works and Materials 52.1 51.1 52.3 54.2 Water, Supply of Working Hours Works, Insurance of 34. 45.1 21.1 54.5 28.2 27 EDITORIAL AMENDMENTS IN 1988 Following publication in 1987 of the Fourth Edition of the Conditions of Contract for Works of Civil Engineering Construction, a number of editorial amendments were agreed by FIDIC. The amendments have been incorporated during reprinting in 1988 and the list below clarifies the differences between the 1988 reprint and the original document. Page 5 Clause 9. The words “as stated in Sub-Clause 9.1 of Part 1 of these Conditions.” have been added to the final line of the first paragraph. Page 6 Sub-Clause 12.2. A comma has been moved from after the word “words” to immediately before the word “other”. The word “Site.” has been capitalised. Page 7 Example performance guarantee. A comma previously appeared between the words “and" and “complete" in the third line of the paragraph beginning “Whereas” The fifth line of the paragraph beginning “Now the Condition previously read “ . . default by the Contract. . .” Page 12 Sub-Clause 21.3. (b) (ii). A full stop has been inserted following “50”. Page 13 Sub-Clause 34. Repatriation of Labour. A comma has been inserted between the words “country)” and “shall”. Page 14 Sub-Clause 34. Epidemics. The word “Contractor.” has been capitalised in the first line. Sub-Clause 34. Alcoholic Liquor or Drugs. The word “Contractor” has been capitalised in the first line. Page 15 Sub-Clause 40.3. This was previously incorrectly listed as 40.2. Page 17 Sub-Clause 49.5. The last line of the first paragraph previously read “…extend beyond 730 days”. Page 20 Sub-Clause 67.3. The word “a.” previously appeared before the bracket on the penultimate line of the Example. Page 21 Sub-Clause 70.2. A comma has been moved from after the word “words" to immediately before the word “other". 28 FURTHER AMENDMENTS IN 1992 The following amendments have been made to the 1988 reprint of the Fourth Edition. In addition, some minor changes in the use of punctuation marks (commas, semicolons, colons and stops), as well as the use of the words “or" and “and" have been introduced to attain uniformity in the style of all Clauses. These minor changes which improve the style, but which have no effect on the meaning of Clauses, have not been listed below. Contents The words “Index” and “Editorial Amendments” have been added at the bottom of the page. Page 1 INTRODUCTION. The words “, subject to minor modifications” have been added, and the word “equally” changed to read “also.”. Page 3 Sub-Clause 1. 1. In the last sentence, the words “for example the name of an International Financing Institution (IFI)” have been deleted. Page 4 Clause 9. In the first paragraph the words “of Part I” have been added. In the second paragraph “I” has been corrected to read “I” Page 5 Clause 12. Sub-Clause 12.2. In the title the word “Adverse” has been changed to read Not Foreseeable (also amended in the Contents and the Index). Page 10 Sub-Clause 2 1. 1, sub-para (a). The words “(the term “cost” in this context shall include profit)” have been added. Page 13 Example Sub-Clause for Supply of Foodstuffs. The words “staff and labour, or his Subcontractors” have been changed to read “ staff, labour and Subcontractors.”. Page 19 Example Sub-Clause for Advance Payment. The words “interim certificate” have been changed to read “Interim Payment Certificate", in both the singular and plural. Clause 67. The first four paragraphs of the commentary have been added. Page 24 Sub-Clause 70. 1. In the formula, the word “Based" has been corrected to read “Base”. Page 25 Example Clause for Bribes. The word “Sub-contractors.” has been corrected to read “Subcontractors”. Example Clause for Details to be Confidential. In the sixth line, the words “the decision of” have been deleted. In the seventh line, the word “award" has been changed to read “determination” Example Clause for Expenditure Restricted. In the commentary and text, the leading capital letters on the words “International Financing Institutions” have been changed to small letters. In the commentary, the word “Articles” has been changed to read “rules or policies”. In the third line, the word “not” has been corrected to read “nor”. EDITORIAL AMENDMENTS (1988). In the last item, the words “Line 21“ have been corrected to read “Page 21”. 29